HomeMy WebLinkAboutRES.801.02-17-1993 1 ..
BILL NO. 93-39 RESOLUTION NO. �"'l�;
A RESOLUTION AUTHORIZING THE CITY MANAGER TO
EXECUTE A CONTRACT FOR PROFESSIONAL SERVICES
WITH BURNS & MC DONNELL FOR CLOSING THE CITY
OWNED LANDFILL
BE IT RESOLVED BY THE COUNCIL OF THE CITY OF CAPE GIRARDEAU,
MISSOURI , AS FOLLOWS:
ARTICLE 1. The City Manager, for and on behalf of the City of
Cape Girardeau, Missouri, is hereby authorized to execute a
Contract with Burns & McDonnell for professional services related
to closure of the existing City-owned landfill. A copy of said
Contract is attached to this Resolution and made a part hereof.
i
PASSED AND ADOPTED THIS ,� /Y�-�� DAY OF ���';�i�� � �� , 19�.
�--ti
� �
L..�'' _ : /�
_ ,c,=.,-=, � 9 l , /, ir � /� i'
�Francis E. Rhodes, Mayor �
ATTEST:
��
;�
/'`...�
s�_�`i[r;,i F' �• � .l'cC tl.�L�
Gayl� L. Conrad, Deputy City Clerk
!� 0 °/a EMPIO �EE • OWNED
, ' � ■
�
♦
/ 1 '
EN6INEERS�AR(HIIEC�S•COHSUf1ANiS
February 3 , 1993
Mr. J. Kensey Russell, P.E.
City Engineer
City of Cape Girardeau
City Hall
401 Independence
P.O. Box 617
Cape Girardeau, MO 63702-0617
Re: Proposal to Provide Professional Services Related
to Closure of Existing City-Owned Landfill
City of Cape Girardeau
Dear Mr. Russell:
Per your Request For Proposal, Landfill Closure which was dated
January 19, 1993 , Burns & McDonnell is pleased to present this
proposal to provide the subject services desired by the City of Cape
Girardeau. We have based our proposal on the information which you
provided in the RFP, our subsequent discussion by phone on January 28,
and on our judgment as to those activities necessary to develop
meaningful, proper closure and post-closure care plans which will be
acceptable to Missouri DNR.
For your convenience, we have structured this proposal in the form of
a Letter Agreement, such that (if the City finds our proposal to be
satisfactory) you could retain our services for this project simply by
signing this document, where indicated.
In terms of pricing, you will note that we have structured our
proposal on a cost reimbursable basis, with a not-to-exceed (ceiling)
fee amount. We believe that this pricing approach is best suited to
the nature of this project. However, if you prefer a different
strategy (such as lump sum) , we are prepared to negotiate some other
approach for reimbursement.
As you requested, we have submitted only information relating to the
scope, pricing, and contractual terms for this project, based on your
statement that the City has already deemed Burns & McDonnell as the
firm most qualified to meet the City' s needs. However, we would also
like to assure the City that we intend to fulfill the other requests
that the City articulated in the RFP - i.e. , that the project will be
managed by Leo Ebel of our St. Louis office (with whom the City is
familiar) , and the technical aspects will be directed by Rick Roberts
(with whom the City is also familiar, and who has been involved in
past solid waste work for the City) .
We sincerely believe that the City staff will be favorably disposed to
our detailed proposal, which follows.
Sunse�Hills Offite Park, 10795 Wa�son Road,St.Louis,Missouri 63127
Phone(314J 871-9016 fax(314J 821-5406
�
�
� � �
Mr. J. Kensey Russell, P.E. Page 2
February 3 , 1993
SCOPE OF SERVICES
The scope of services that Burns & McDonnell (hereinafter CONSULTANT)
proposes to perform to accomplish the desired objectives stated by the
City of Cape Girardeau (hereinafter CLIENT) is defined, for purposes
of this proposal, by the enclosed List of Proposed Major Tasks, dated
January 29, 1993 .
RESPONSIBILITIES OF CLIENT
It is CONSULTANT's understanding that CLIENT will provide the
following assistance, information, or items:
A. Assistance by placing at CONSULTANT's disposal all available
current information pertinent to this assignment, including
previous plans, specifications, reports, and other data.
B. Aerial photographic site topography map (1990 version) with
two-foot contour intervals [including AutoCad disk copy of
map, if available] .
C. Landfill property boundary survey, prepared by registered
land surveyor [including AutoCad disk copy of survey, if
available] .
D. Map showing current topography of site (reflecting contours
of site created by landfilling activity since 1990)
[including AutoCad disk copy of map, if available] .
E. A current facility map showing: limits of solid waste
landfilling activity on site; locations of groundwater
monitoring wells; locations of gas monitoring wells; and
location of leachate collection, containment, and
treatment/disposal facilities [including AutoCad disk copy
of map, if available] .
F. Available, as-built drawings, specifications, design notes,
etc. defining the configurations of the above systems.
G. Proper liaison with the City of Cape Girardeau staff
involved in this project.
H. Reasonable access to other data and records related to this
assignment that CONSULTANT may determine a need for.
CONSULTANT shall rely on information, drawings,etc. made available by
the CLIENT as accurate, based only on verification of certain key
parameters (if necessary) .
�
0
� , •
Mr. J. Kensey Russell, P.E. Page 3
February 3 , 1993
COMPENSATION
A. Amount of Payment and Statements
1. For services performed, CLIENT shall pay CONSULTANT the sum
of the amounts determined as follows:
a. For time spent by personnel directly related to project
performance, payment shall be at hourly rates indicated
in the enclosed Exhibit A, "Schedule of Hourly Billing
Rates" , Form BMR1092 . Such rates include employee
compensation, overhead expense, and profit. The
schedule is effective until May 31, 1993 and may be
subject to revision thereafter.
b. For expenses incurred by CONSULTANT, such as authorized
travel and subsistence (including airfare, food,
lodging, automobile rental, commercial services, and
other incidental expenses) payment shall be at the
actual cost to CONSULTANT.
c. For document reproduction expenses, long-distance
telephone calls and/or facsimile transmissions, company
vehicle usage, testing apparatus rental, computer use,
and other direct expenses, payments shall be based on
CONSULTANT' s standard rates in effect at the time such
services are employed. Exhibit B, enclosed, lists
current rates in effect for common direct expenses.
d. For professional services rendered by others under
subagreement to CONSULTANT, such as surveying, soil
boring, laboratory analytical testing, or other
activities authorized by CLIENT, payments shall be
based on cost billed to CONSULTANT by performing
entity, plus ten (10) percent surcharge as a
coordination/handling charge.
e. Statements from CONSULTANT to CLIENT requesting
payments as described above shall be handled in the
manner prescribed in the Notes on the previously
described Form BMR1092 .
On the basis of the above scope and payment terms, CONSULTANT proposes
to complete the required services for this project for a cost not to
exceed Twelve Thousand Three Hundred dollars ($ 12 , 300. ) . A breakdown
of this amount, provided as background information on1v, is enclosed.
The terms of compensation and other terms and conditions governing
this work shall be as defined by the attached Burns & McDonnell
standard Terms and Conditions For Professional Services (Form No.
TRMSCONS: l-3-92) .
. �
0
� � •
Mr. J. Kensey Russell, P.E. Page 4
February 3 , 1993
SCHEDULE
CONSULTANT proposes to complete the work defined herein within eight
(8) weeks following CLIENT's notice to CONSULTANT to proceed with the
above described services. The adherence to this schedule is, of
course, contingent on timely receipt from the CLIENT of information
needed by the CONSULTANT to carry out this assignment, and prompt
review and return of all documents submitted to CLIENT by CONSULTANT
for comment/approval.
We sincerely appreciate this opportunity to be of service to the City
of Cape Girardeau. If there are any questions concerning our
proposal, please contact Leo Ebel, Rick Roberts, or me. If this
proposal is acceptable, please siqn and return one copy to us for our
files.
Res e fu ly Su itted,
D . Rob rt T. Berr , P.E.
Vice Pr sident an
Manager of St. Lou' s Office
ACCEPTED FOR
CITY OF CAPE GIRARDEAU:
J
,
By: :.// � - �,�
Title: j.r� {��a:�%�'r;^:tu��'
_,
Date: ���/�" .<f,�
CITY OF CAPE GIRARDEAU
DEVELOPMENT OF CLOSURE AND POST-CLOSIIRE CARE PLANS
FOR EXISTING SOLID WASTE MUNICIPAL LANDFILL
LIST OF PROPOSED MAJOR TASRS
1. Attend a project initiation meeting to discuss closure plan/goals
with City of Cape Girardeau staff.
2 . Review existing landfill records, maps, drawings, and details (as
previously described in the text of this Letter Agreement) to
determine areas requiring closure.
3 . Visit landfill site to observe current conditions, including:
• determination of depth and integrity of cover material
• evaluation of condition/suitability of surface vegetation
• analysis of condition/functionality of existing stormwater
control devices and evaluation of future needs
• analysis of condition/functionality of existing leachate
management system and evaluation of future needs
• analysis of condition/functionality of existing gas
monitoring system and evaluation of future needs
4 . Prepare a landfill facility site map (from information and maps
furnished by City, supplemented by additional data gathered above
and B & McD experience) showing the proposed final contours,
property boundary (as surveyed) , surface water run-on/run-off
patterns and control structures, gas monitoring well system, and
leachate management system to be maintained after closure.
5. Prepare an engineering report describing the proposed closure
plan to be implemented and the post-closure care activities to be
performed. Report will include an estimate of cost (both for the
closure plan implementation and the post-closure activities
performance) for both the landfill area and adjacent borrow areas
(as required) .
6. Submit a draft of the above engineering report to the City for
review and approval.
7. Attend one meeting with City staff to discuss/resolve City review
comments on draft engineering report.
8e Incorporate appropriate City review comments and finalize
engineering report. Transmit final engineering report to City
for City's submittal of report to Missouri DNR for approval.
9 . Assist City in responding to Missouri DNR questions/comments on
engineering report submitted for approval.
10. Revise engineering report, as necessary, to incorporate agreed-on
modifications required by Missouri DNR and reissue final, revised
engineering report to City for use.
11. Provide appropriate management/administration of B & McD staff
involved in project (including quality control) .
1 of 2
CITY OF CAPE GIRARDEAU
DEVELOPMENT OF CLOSURE AND POST-CLOSURE CARE PLANS
FOR EXISTING SOLID WASTE MUNICIPAL LANDFILL
LIST OF PROPOSED MAJOR TASRS (Cont�d)
Basic Assumptions:
A. Additional meetings and/or other elements of work
specifically authorized by CLIENT for CONSULTANT to perform
that are agreed to be beyond the scope of this agreement
shall be compensated for on a "time-and-materials" basis,
with labor charges and direct expense reimbursement in
accordance with the enclosed Exhibits "A" and "B" .
B. Design of any gas control, groundwater monitoring, leachate
control, and/or other such systems that may be found to be
necessary or required by Missouri DNR, are considered beyond
the scope of this Agreement.
By: Burns & McDonnell
February 1, 1993
2 of 2
BURNS & MCDONNELL ENGINEERING COMPANY, INC.
TERMS AND CONDITIONS FOR PROFESSIONAL CONSULTING SERVICES
January 1, 1991
1. PAYMENTS TO ENGINEER E. The Engineer will not be liable to Owner for any loss or damage
A Compensation will be as stated in the qgreement.Statements are relating to the Services which Owner sustains after the expiration of a
payable upon receipt.A late payment charge of 1.5 percent per month period oi one year from the date of substantial completion of
will be added to ail amounts not paid within 30 days oi statement performance of the Services and immediately reported in writing to
date, accruing from the statement data. My costs incurred by Engineer.
Engineer in collecting any delinquent amount shall be reimbursed by
Client. tf a portion of Engineer's statement is disputed,the undisputed F. The obligations and remedies stated in this Paragraph 3,
portion shail be paid by Client by the due date. Ctient shall advise Professional Responsibility, are the sole and exclusive obligations oi
Engineer in writing of the basis for any disputed portion of any Engineer and remedies of Client, whether liability of the Engineer is
statement. based on conVact,warranty,tort,or otherwise.
8. Taxes as may be imposed by state and local authorities,other than 4. GENERAL RESPONSiBILITIES OF CLIENT
federal and state income tax and Kansas City, Missouri earnings tax, Client shall,within a reasonable time, so as not to delay the services
shail be in addition to the payment stated in the attached P`qreement. of Engineer:
2. INSURANCE A. Place at the Engineer's disposal all available information pertinent
During the course of performance of its services, Engineer will to Engineer's services. Engineer shall rely on information made
maintain the foilowing minimum insurance coverages: available by Client as accurate without independent verification.
B. Examine all documents presented by Engineer and render
Type of Coverage Llmita of Uabilfty decisions pertaining thereto.
Workers'Compensation Statutory C. Give prompt written notice to Engineer whenever Client observes
Employers'Liability $500,p00 Each Accident or otherwise becomes aware of any detect in Engineer's services.
Commercial General D. Arrange for access to and make ail provisions for Engineer to enter
Liability $1,000,000 Combined upon public and private property as required for Engineer to perform
Bodily Injury and Single Limit its services.
Property Damage
E. Provides such professional legal, accounting, finandal and
Automobile Liabiliry insurance counseling services as may be required by the Client or
Bodily Injury and $1,000,000 Combined reasonably requested by the Engineer for the Project.
Property Damage Single Limit 5. PERIOD OF SERVICE
tf requested,Engineer will provide to Client certificates as evidence of The provisions of this Agreement have been agreed to in anticipation
the specified insurance. of the orderly and continuous progress of the Project through
completion of the services stated in the Agreement. Engineer's
3. PROFESSIONAL RESPONSIBILITY obligation to render services hereunder wiil extend for a period which
A Engineer will exercise reasonable skill, care, and diiigence in the may reasonably be required for the compietion of said sarvices.
performance of its services and will carry out its responsibilities in g, COMPUTER MODELS
accordance with customarily accepted good professional practices. If
the Engineer fails to meet the foregoing standard, Engineer wiii Engineer may use or modify its proprietary computer models in
perform at its own cost, and without reimbursement irom Client,the service of Client under this Agreement, or Engineer may develop
professional services necessary to correct errors and omissions which computer models during its service to Ciient under this f�qreement.
are caused by Engineer's failure to comply with above standard,and Such use, modification or development by Engineer does not
which are reported to Engineer within one year from the completion of constitute a license to Client to use or modify Engineer's computer
Engineer's services for the project. modeis. Said proprietary computer modeis shall remain the sole
property of the Engineer.Ciient and Engineer wili enter into a separate
B. In addition, Engineer will be responsible to Client for damages license agreement if Client wishes to use Engineer's computer
caused by its negligent conduct during its activities at the Project site models. �
to the extent covered by Engineer's Commercial General Liability and
Automobile Liability Insurance as specified in Paragraph 2. 7. ELECTRONIC MEDIA
My electronic media (computer disks, tapes, etc.) furnished
C. In no event will Engineer be liabie for any spedal, fndirect or respecting Burns & McDonnell's services are for Client information
consequential damages including, without limitation, damages or and convenience only. Such media are not to be considered part of
losses in the nature of increased Project costs, loss of revenue or Burns 8�McDonnell's instruments of service. Due to the potential that
profit,lost production,claims by customers of Client,or governmental information contained in electronic media can be modified by Client
fines or penalties. . or others, Burns 8� McDonnell, at its option, may remove all indicia of
D. The Engineer's aggregate liability for all damages connected with its ownership and invoivement irom each electronic display.
its services for the project not excluded by the preceding
subparagraph will not exceed the compensation paid tor the Services.
(continued on reverse side)
Fortn TAMSCANS•1 5�82
BURNS & MCDONNELL ENGINEERING COMPANY, INC.
TERMS AND CONDITIONS FOR PROFESSIONAL CONSULTING SEAVICES
January 1, 199i
Burns 8� McDonnell shall not be liable for loss or damage directly or 11. CHANGES
indirectly, arising out of use of electronic media including, but not Client shall have the right to make changes within the general scope
limited to, any loss of business or incidental or consequential of Engineer's services,with an appropriate change in compensation,
damage.Client shall assume all risk and release,indemnify and holds upan execution of a mutuaily acceptable amendment or change order
harmless Burns & McDonneil, its officers, directors, employees, signed by an authorized representative of the Client and the President
servants, agents,successors and assigns,from and against each and or any Yce President of the Engineer.
every claim or cause of action that Client or others may have or which
may arise in the tuture respecting use of the electronic media. 12 TERMINATION
8. DOCUMENTS Services may be terminated by the Client or Engineer by seven (7)
days' written notice in the event of substantial failure to perform in
All documents prepared by Engineer pursuant to this qgreement are accordance with the terms hereof by the other party through no fauit
instruments of service in respect of the Project specified herein.They of the terminating party.ff so terminated,Client shail pay Engineer all
are not intended or represented to be suitable for reuse by Client or
others in extensions of the Project beyond that now contempiated or amounts due Engineer tor all services properly rendered and
on any other project.Any reuse by Client without written verification or expenses incuned to the date of receipt of notice of termination,pius
adaptation by Engineer ior the specific purpose intended will be at reasonable costs incurred by Engineer in terminating the services.
ClienYs sole risk and without liability or legal exposure to Engineer.
13. DISPUTES
9. ESTIMATES AND PROJECTIONS In the event that a dispute should arise relating to the performance of
Eatimates and projections prepared by Engineer relating to loads, the services to be provided and should that dispute resuit in litigation,
interest rates and other financial analysis parameters, construction it is agreed that the prevailing party shall be entitled to recover all
costs and schedules, operation and maintenance costs, equipment reasonabie costs of litigation, including staff time, court costs,
characteristics and performance, and operating results are based on attorneys'fees and other related expenses.
Engineer's experience, qualifications and judgment as a professional
consuitant. Since Engineer has no control over weather, cost and 14. RIGHTS AND BENEFITS
availabiliry of labor, material and equipment, labor productivity, �9ineer's servicas will be performed solely tor the benefit of the
construction conVactor's procedures and methods, unavoidable Client and not for the benefit of any other persons or entities.
delays, construction contractor's methods of determining prices, •
economic conditions,government regulations and laws (ncluding the �5. EtJTiRE AGFiEEMENT
interpretation thereofl, competitive bidding or market conditions and These Terms and Conditions and the attached Acueement contain the
other factors affecting such estimates or projections. Engineer does
not guarantee that actual rates, costs, performance, schedules, etc., entire agreement between the Engineer and Client relative to the
will not vary irom estimates and projections prepared by Engineer. �ope of Services specified in the P`qreement. All previous or
contemporaneous agreements, representations, promises and
10. ON-SITE SERVICES conditions relating to Engineer's services described in the Agreement
are superseded. Since terms contained in purchase orders do not
Project site visits by Engineer during construction or equipment generaily apply to professional services, in the event Ciient issues to
installation, or the furnishing of Project resident representatives shall Engineer a purchase order,no preprinted terms thareon shall become
not make Engineer responsible for construction means, methods, a part of this Agreement. Said purchase order document, whether or
techniques, sequences or procedures; for construction safety not signed by Engineer, shall be considered as a document for the
precautions or programs; or for any consVuction cantractor(s') failure Client's internal management of its operations.
to perform its work in accordance with the the drawings and
specifications.
[The remainder of this page was left blank intentionally.]
Fortn TAMSCONS-2 �92
C
Z
W
�W m
J �
c
.�
N N N O CO N N O M N � N Z W � �
� O � C �
UV < m `� � �
t I V � �?i W •V c
LL � C �C C C '�6
nO00a0a000N �tOaD y � � N E � � c9M
J U U � � � �' ° � c�i ❑ rn
J J O O O c Q a> �
�i W a a a w U U �
ZZc� aaovcooNNvvo �n,� Z w 2�
a W W V O � �
� �
� N d a � a w U U �
N3O t0 c0 a0 N a N � a a O �
� 0 W J
UD aV
HN
y J
9 a � C9 O O O N a O N O N GD N
a
GZU � U
Q � .
? � N O O O O O O O O r N �A � � N � � � � � �
yZ � � a CV cON �
0 � � � o vi f»u9 v�v� v�i� ^
VN aV HU r►
LL � � y � p T O � f� (O � � � N (V O
ZW H � � �A � : n6n9H3u�9H �� � N
go ���� �� �
� r► N
LL
� �
� a � � • aa g �a
Wa = = � cncn � ocn
� U .xv, = o � °° Ncc�iommcnna � �I a �m,� � o0
WO � � � � � � � � � I f f
� � I I I
oU
Q N II
Q
� O N
� Z U
Y � Z
� QN tWA W Z
J � � O Z �
Q c � U W Z O
cn � r � �n 2 � x � �
� � W � .. � .: ,;• .. u� z
0 �E p � CO � �tS a 0 i6 � � � W �
d g � � p� o o � O � U � c�i � a�i c � W W W
� _ wa`� � aYzr HO � � oo [LN �Q QU
� E -- � co .
� a�i a�i m � o N m � � m � d d � °� V � � � I
U � �� m c � c o �� � � � � � o o � tO Q � W O
t m � Q I
~ � � S E m � c Z � � a J EQ � �� LL � N � � O7
� Y :F u� C � � � � �p ~ () � H a � W � G
� � �.N tQ .� � o
I � N °- d � o g- 3 in � U J
s > �' d c�i � •c ~ Q
� c N �� o � � a� ° -Ep O
� 01� — V � �> N m � l6 �'
O N � �7 � � � C 'p�a m
a �� � vU V�' � C7 E
� 3 � �' � 3 V � �'n
� .dv aa� a�' � ° �
C � C � � � V q ! 'C
U � Uaa � S ¢ a�[ a �
o N
W
� Y �- N M � � (O � aD O� � � Z
� W
a
� �
. Exhibit "A"
Schedule of Hourly Professional Service Billing Rates
Position Classification Hourly
Classification Level Billing Rate
General Office'` 1 $12.50
2 13.50
3 19.50
Technician* 4 . 22.00
5 26.50
6 31.50
Assistant* 7 35.00
8 50.00
9 55.50
Staff 10 58.50
11 64.50
Senior . 12 70.50
13 76.00
Associate 14 87.50
15 95.00
Principal 16 96.50 �
17 101.00
Notes
1. Position classifications listed above refer to the firm's internal classification system for employee compensation. For example, -
"Associate,""Senior,"etc.,refer to such positions as"Associate Engineer,""Senior Architect,"etc.
2. The hourly rates shown above are effective for services through May 31, 1993,and are subject to revision thereafter. �
3. For any nonexempt personnel in positions marked with an asterisk (*), overtime will be billed at 1.5 times the hourly labor
billing rates shown.
4. Project time spent by corporate officers will be billed at the Principal rate (Level 17)plus 25 percent.
5. Monthly statements will be submitted for payment covering services and expenses during the preceding month.
BMR1092
Exhibit "B"
BURNS & MCDONNELL ENGINEERING COMPANY, INC.
DIRECT EXPENSE REIMBURSEMENT SCHEDULE
TRANSPORTATION:
Personal/Companv Vehicle Use
For occasional project-related use, cost is $0.28 per actual mile (all inclusive; i.e., no separate
charges for gas, oil, other consumables, or maintenance are incurred)
Commercial Carrier Use
Actual cost per ticket/invoice, from airline, car rental agency, etc.
SUBSISTENCE:
For lodging, meals, automobile rental, and other reasonable living expenses related to project-
related "field" assignments outside of normal work location, reimbursement shall be at actual
costs documented by properly completed expenses account (with appropriate receipts), as
approved by Project Manager.
COMPUTER FACILITIES:
Micro Computer Use (Computation or Word Processinq)
Rate is $11.00/Hr. (logged-on clock time, does not include user labor)
Micro Computer Use (CADD)
Rate is $21.00/Hr. (logged-on clock time, does not include user labor)
Plottinq (CADD - qenerated drawinQs)
For "working" drawings plotted on paper, vellum, or other non-durable media, no charge (costs
are included in CADD computer use rate).
For finished drawings plotted on mylar, cost is $5.00/sq. ft. (all inclusive, i.e. including labor).
For "finished" drawings plotted on vellum, cost is $3.50/sq. ft. (all inclusive).
REPRODUCTION:
_X_erographic CopvinQ (black and white)
For 8 1/2" x 11" sheets, onto bond paper - $0.05/page
For 8 1/2" x 14" sheets, onto bond paper - $0.08/page
For 11" x 17" sheets, onto bond paper - $0.16/page
Xeroqraphic Copyinq (color)
For 8 1/2" x 11" sheets, onto bond paper - $1.00/page
For 8 1/2" x 14" sheets, onto bond paper - $1.25/page
For 11" x 17" sheets, onto bond paper - $2.00/page
Blueprintinq
For all size sheets, cost is $0.08/sq. ft.
Paper Sepia Reproducible Production
For all size sheets, cost is $0.36/sq. ft.
Page 1 of 2
DIRECT EXPENSE REIMBURSEMENT SCHEDULE
(continued)
Mvlar Reproducible Production
For all size sheets, cost is $2.75/sq. ft.
Other "Outside" Services
Reimbursement shall be at actual cost.
COMMUNICATIONS:
Lonq Distance Telephone/Fax
Reimbursement for all such project-related use shall be at actual cost, as supported by AT & T
billing summaries.
Expedited Deliverv Services
Reimbursement for all such project-related use shall be at actual cost, as supported by Federal
Express or other commercial courier service billing summaries.
Page 2 of 2
r w
AMENDMENT NO. 2
To
AGREEMENT For PROFESSIONAL ENGINEERING SERVICES
Between
BURNS & McDONNELL WASTE CONSULTANTS, INC.
Overland Park, Kansas
And
CITY OF CAPE GIRARDEAU, MISSOURI
This Contract Amendment is made by and between Burns & McDonnell Engineering Company, Inc.,
(hereinafter ENGINEER) and City of Cape Girardeau, Missouri (hereinafter CLIENT) this ��?r�C�day of
i " �1 i 9ss•
Whereas, it is the mutual desire of the parties hereto to amend the Agreement for Professional
Engineering Services entered into on February 18, 1993 (hereinafter called the Existing Agreement).
Therefore, it is hereby agreed that the Existing Agreement be amended as follows:
SCOPE OF SERVICES
The following is our understanding of the Scope of Services to be provided by the ENGINEER of
CLIENT, in connection with this Amendment No. 2:
This Amendment will be deemed a part of, and be subject to, all terms and conditions of the Existing
Agreement. Except as modified below, the Existing Agreement will remain in full force and effect.
A. Review information furnished by the CLIENT concerning new property ownership, deeds, and
description for the Solid Waste Municipal Landfill. Prepare a 24" x 36" drawing showing the new
landfill property and adjoining properties.
B. Prepare closure certification documents for the CLIENT's Solid Waste Municipal Landfill and submit
same to CLIENT for approval, signature, and submittal to the Missouri Department of Natural
Resources.
RESPONSIBILITIES OF CLIENT
CLIENT will provide, in connection with this Amendment 2, information as specified in the Agreement for
Professional Engineering Services and as follows:
A. CLIENT to provide ENGINEER with a registered land surveyor's plat of the new landfill property
showing the revised property lines.
B. CLIENT to provide ENGINEER with current property deeds and descriptions of the Solid Waste
Municipal Landfill.
CAPEFILL.AM2
03/26/96 �
. .. 4._-.
C. CLIENT to provide ENGINEER with the location of the new gas monitoring wells installed along the
new property lines and changes to the property access, perimeter fencing, and structures
remaining on the site.
PERIOD OF SERVICE
ENGINEER shall complete work within six (6) weeks following receipt of written notice from CLIENT that
CLIENT has approved this amendment and receipt of the information to be provided by CLIENT.
COMPENSATION
For the services performed, CLIENT shall pay ENGINEER the sum of amounts determine under the
COMPENSATION section of the Existing Agreement as amended. However, total payment for the Scope
of Services described herein is estimated to be One Thousand Five Hundred Fifty-Eight Dollars
($1,558.00). The maximum for the Scope of Services shall not exceed the estimated payment without
written approval of CLIENT.
�
CAPE GIRARDEAU, MISSOU�
.� ,-
� _ BY.
� Title I���ii�hr,Ff ��. �'�i�le✓� �"�tv �iGv�Qv,:a r
,�
BURNS & McDONNELL WASTE CONSULTANTS, INC.
� � ,
�" ' "
By ; l.c;�/ . .%:��-�
Preside
CAPEFILL.AM2
03/26/96 2