The URL can be used to link to this page

Home My WebLink AboutRES.848.08-02-1993 , BILL NO. 93-168 RESOLUTION NO. �� A RESOLUTION AUTHORIZING THE CITY MANAGER TO EXECUTE A CONSTRUCTION CONTRACT WITH PENZEL CONSTRUCTION COMPANY FOR THE ENTRANCE ROAD AT THE CAPE GIRARDEAU MUNICIPAL AIRPORT BE IT RESOLVED BY THE COUNCIL OF THE CITY OF CAPE GIRARDEAU, MISSOURI, AS FOLLOWS: ARTICLE 1. The City Manager, for and on behalf of the City of Cape Girardeau, Missouri, is hereby authorized to execute a Construction Contract with Penzel Construction Company for the entrance road at the Cape Girardeau Municipal Airport. A copy of said Contract is attached to this resolution and made a part hereof. PASSED AND ADOPTED THIS �� /,'� � � ��1� ` DAY OF �.�i_�'! r, �, � Zg �� 1 J ��s' , , � �%. Francis E. Rhodes, Mayor ATTEST: r �'� � .� �''� r.-�--� f^:.�y, �f,:, r�!��_� Kimberly�A. Pruett, Deputy City Clerk City of Cape Girardeau, Missouri Cape Girardeau MUNICIPAL AIRPORT FAA AIP No. 3-29-0013-04 Entrance Road Improvements CONSTRUCTION CANTRACT THIS AGREEMENT, made and entered into this �� day of;� �f- ; � 19�/�'� by and between the City of Cape Girardeau, Missouri, Party of the First Part, hereinafter referred to as the OWNER and n ,P� onsfir„�,�- ; �n .om��Y Party of the Second Part, herei.nafter referred to as the CONTRACTOR. WITNESSETH TFiAT: WHEREAS, the OWNER has called for bids for the construction of Airport Improvements as set out in the Specifications and Plans. WI�REAS, the CONTRACTOR is the lowest and best bidder for the construction of � said improvements hereinafter set out, pursuant to the published calls for bids under said Plans and Specifications. NOW TF�REFORE, the CONTRACTOR AGREFS WITH TI� Owner to commence and complete the construction of City of Cape Girardeau Municipal Airport Entrance Road Improvements and other tasks as designated in the Project Plans and Specifications for the prices bid, based upon the estimated quantities, the total being: ( $396, 175. 45 ) Thr H �ndr Nine y-Six Thousand One Hundred Seventv-Five and 45/100--- such sum bei.ng the agreed amount upon which bonds and liabilities are based, and at his own cost and expense furnish all materials, supplies� labor, machinery, equipment, tools, supervision, bonds, insurance, taxes, permits, and other accessories and services necessary to complete the said construction in accordance with the conditions and prices stated in the Proposal attached hereto and made a part hereof� and in accordance with the General Provisions and Specifications, and in accordance with the Plans, which include all maps, plats, blueprints, and other drawings, and written or printed explanatory matter hereof. The CONTRACTOR agrees to fully complete a.11 work under this Contract within 90 calendar days from the date of the Notice to Proceed. The OWNER agrees to pay the CONTRACTOR in correct funds for the performance of the Contract in accordance with the accepted Proposal therefore, subject to additions and deductions, a.s provided in the Specifications, and to make payment on account thereof as provided below: As soon as is practicable after the first of each calendar month, the OWNER will make partial payments to the CONTRACTOR for work performed during the preceding calendar month, based upon the Engineer's estimate of work completed, said estimate being certified by the CONTRACTOR and accepted by the OWNER. Except as otherwise provided by law, ten percent (lOx) of each approved estimate sha11 be retained by the OWNER or his representative. Upon final completion end acceptance by the OWNER and ENGINEER, the ENGINEER sha11 then issue a Final Estimate of work done based upon the original contract and subsequent changes made and agreed upon, if any. 934o5-01 cs-3 Time is hereby expressly declared to be of the essence of this contract, and the time of beginning, manner of progress and time of completion of the work hereunder, shall be and are essential conditions hereof. The CONTRACTOR agrees to commence the work within ten (10) calendar days from the date of the issuance of the Notice to Proceed, and to _proceed with the construction of the work and to prosecute the work with an adeguate force and in a manner so as to complete the work within the time stipulated herein. If the Contractor fails to complete the contract within the time stipulated herein, the CONTRACTOR agrees to pay the OWNER, as liquidated damages� the sum of Two hundred dollars per day for each calendar day of delay in completion, said a.mounts being fixed and agreed upon by and between the parties hereto. Because of the impracticability and extreme difficulty in fixing and SSC@rtaining the actual da.mages the OWNER wauld in such event sustain, said amounts are to be presumed by the parties to this contract to be the amounts of damage the OWNER would sustain. Said amounts of liquidated damages shall be deductible from any amount due the CONTRACTOR under Final Estimate of said work, after the completion thereof, and CONTRACTOR shall be entitled only to the Final Estimate� less such amounts of - liquidated damages. If the CON'IR.�CTOR is delayed at any time i.n the progress of the work by any act or neglect of the OWNEF3 or of his employees, or by any other CONTRACTOR employed by the OWNER, or by changes ordered in the work, or by strikes. lockouts, fire, unusual delay in transportation, unavoidable casualties or any causes beyond the CONTRACTOR's control, or by delay authorized by the Engineer pending arbitration, or by any cause which the Engi.neer shall decide to justify the delay, then the time of completion may be extended for such reasonable time as the Engi.neer may decide. No such extension shall be made for delay occurring more than seven (7) days before a claim therefore is made in writing to the Engineer. In the case of a continuing cause of delay, only one claim is necessary. In the event the CONTRACTOR abandons the work hereunder or fails, neglects or refuses to conti.nue the work after ten (10) days written notice, given the CONTRACTOR by the OWNER or by the ENGINEER, then the OWNER sha1.1 have the option of declaring this contract at an end, in which event, the OWNER shall not be liable to the CONTRACTOR for any work theretofore performed hereunder; or requiring the surety hereto, upon ten (10) days notice, to complete and carry out the contract of the CONTRACTOR, and in that event, should the surety fail, neglect or refuse to carry aut said contract; said OWNER may complete the contract at its own expense,and maintain an action against the CONTRACTOR and the surety hereto for the actual cost of same; together with any da.mages or other expense sustained or incurred by the �WNER in completing this contract less the total amount provided for hereunder to be paid the CONTRACTOR. upon the completion of this Contract. Should any legal action be brought to construe or enforce the terms of this contract, �urisdiction and venue sha11 be proper only in the Circuit Court of Cape Girardeau County, Missouri. In the event any covenant, provisions, or condition contained in this contract is heid invalid by any court of competent �urisdiction, or otherwise appears to the parties hereto to be invalid, such invalidity shall not affect the validity of any other covenant, condition� or provisions herein contained; provided, however, that the invalidity of any such covenant, condition, or provisions does not materially prejudice either party in its respective rights and obligations contained in the remaining valid provisions of this contract. 93405-01 cs-4 � This Contract shall be binding upon the heirs, representatives, successors, or assigns of the parties hereto, includi.ng the surety. It is hereby further agreed that any reference herein to the "Contract" sha11 include alI "Contract Documents" as the same are listed and described in Section B of the Special Provisions issued in connection with the construction of FAA AIP No. 3-29-0013-04. Entrance Road . Improvements and said "Contract Documents" are hereby made a part of this agreement as fully as if set out at herein, and that this contract is limited to the items in the proposal as signed by the "Cantractor" and i.ncluded in the "Contract Documents". IN WITNESS WHEREOF, the Party of the First Part and the Party of the Second Part, respectively, have caused this agreement to be duly executed in day and year first herei.n written in Five copies, all of which to e11 intents and purposes sha11 be considered as the original. - �.-- SPONSOR, Party oF the First Part � City of Cape Girardeau Attest gy; �a��,� � .� ; � ° Mayor . �''-�J-tii%� ��/��0/C '� City' Clerk ATTEST: CONTRACTOR, Part of Second Part �� I . � �`!�y` '�� -�� j;� �f'�' � pENZEL CONSTRUCTION COMPANY, INC. �� ; ' BY: � , , � Carl G. Penzel , _` _ _._ �`' . President � ; ' � ' Office or Position of Signer CERTIFICATE OF DIRECTOFi OF FINANCE I certify that the expenditure contemplated by this document is within the purpose of the appropriation to which it is to be charged and there is an unencumbered balance of appropriated available funds to pay therefore. �v-z.: /?/ [ ��1�.-e��,.,�,,� Director of Finance 934o5-oi cs-5 THE AMERICAN INSTITUTE OF ARCHITECTS Bond #: 111 1928 2447 AIA Docurnent A312 Performance Bond My singular reference to Contr'actor, Surety, Owner or vther party shall be considered plural where appiicable. CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business): Penzel Construction Company, Inc. The American Insurance Company 777 San tiarin Drive P.O.Boa 330 Novato, California 94998 (314) 569-7300 Jackson, Hissouri 63755 OWNER (Name and Address): City of Cape Girardean City Hall P.O. Boz 617 Cape Girardeau, MO 63702 CONSTRUCTION CONTRACT Date: ��, �`�9� Amount:T�ea Hundred Ninety Siz Thousand One Hundred Seventy Five and 45/100 Dollars( $396,175.45) Description �N8R1@ 8f1CI LOCBtIOfI�:P��No. 3-29-0013-04 Entranca Road Improvements to Cape Girardeau Municipal Airport BOND Date (Not earlier than Construction Contract Date): s a2, �993 Amount:T�ee Hundred Ninety Sia Thousand One&undred Seventy Five and 45/100 Dollars( S396,175.45) Modifications to this dond: � None ❑ See Page 3 CONTRACTOR AS PRINCIPAL SURETY Company: (�er�orate Seal) Company: (Corporate Seal) Penzel Constzuction C�panv, Inc. The American Insurance Company _ i , r� ,:- , � <� . , -,.�"i ' .. , ,._, . . : ,. --------� Signature: — '"' —� a '" �— Signature: _ � Name and TiY{e L'3rl G. Penzel, P�esident Name and Title Helissa D. Evans Attorney-In-Fact (Any additional signatures 2.ppear on page 3} (FOR INFORMATION ONLY - Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or other party): Lockton Insurance Agency P.O. Boa 8418 Prairie Village, KS 66208 AIA DOCUMENT A312 - PERFORMANCE BOND AND PAYMENT BOND - DECEMBER 1984 ED. - AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312-1984 1 1 The ContraCtor and the Surety, jointly and sever�llv, �ind themse�ves, ;heir heirs, executors. administra�ors, which it may be I�able to �he O��ner and, as successors and assi�ns to the Owner ior the errormance S�O� �s practic�ble �iter the amount is deter- P mined, tender payment thereior to the �t the Construction Contract,which is incorporated herein 'oy reference. O�vner; or '_ li the Contractor perrorms the Construction Contract, '2 Deny liabilitv in whole or in part and noti'ry the the Surety and the Contractor shall have no obligation Owner citing reason; thereror. under this Bond, e�ccept to participate in conferences as � �f the Surety does not proceed as provided in Paragraph arovided in Subparagraph 3.1. �with reasonable promptness, th�Surety shall be deemed 3 if there is no Owner Derault, the Surety's obli�ation addtional rvritten InotBendoimethe O�vneretoe hePS�retv under this Bond shall arise after: demandino that the Surety perform its oblioations under 3.1 The Owner has notified the Contractor and the this Bond, and the O�vner shall be entitled to enforce anv Surety at its address described in Paragraph �0 belo�v �emedy available to the Ow•ner. Ir the Surety proceeds as that the Owner is considerino decfaring a Contractor P�ovided in Subparagraph 4.-i, and the Owner retuses the Derault and has requested and attempted to arrange a Payment tendered or the Surety has denied liability, in conrerence with the Contrzctor and the Surety to be �^'hole or in part,wichout rurther notice the O�vner shall be held not later than rirteen days arter receipt or such entitled to enrorce anv remedv available to the Owner. notice to discuss methods or performing the Construc- 6 Atter the Owner has terminated the Contractor's right tion Contract. If tne Owner, the Contractor and the to complete the Construction Contract, and ir the Suretv Surety agree, the Contractor shall be allowed a reason- elects to act under Subpara�raph -�.1, -t.?, or a.3 above, able time to perrorm the Construction Contract, out then the responsibilities or the Surety �o the O�vner ;hall such an agreement shall not tivaive the O�vner's ri�ht, if not be greater than those of the Contractor under the any, subsequently to declare a Contractor�etault; and Construction Contract, and the responsibilities oi Ihe 3.2 The Owner has declared a Contracior Deiault and Owner to the Surery shall not be oreater than those oE the �ormaliy terminated the Contractor"s nght ro complete Owner under che Construction Contract.To the limit oi the the contract. Such Contractor �e�ault shall not be de- amount or this Bond, but subject to commitment by the clared earlier than hventy days aiter the Contractor and Cwner or the Balance oi the Contract Price to mitigation of the Suretv have received notice as provided in Sub- costs and damages on the Construction Contract, the Sure- paragraph 3.1; and ty is obli�ated without duplication for: 3.3 The Owner has agreed to pay the Balance or the 6.1 The responsibilities of the Contractor ror correc- Contract Price to the Surety in accordance with the tion or deiective work and completion �r the Construc- terms o� the ConstrUction Contract or to a contractor ��on Contract; selected to pertorm the Construction Contract in accor- 6.2 Additional legal, desi�n pro�essional and delay dance with the terms oi ;he contract with the Owner. costs resulting from the Contractor's Oerault, and re- -� When the Owner has satisried the conditions or Para- sulting rrom the actions or failure to act of the Suretv �raph 3, the Surety shall promptiv and at the Surety's ex- under Paragraph 4; and ' �ense take one or the rollowing actions: 6.3 �i uidated dama� 9 aes, or it no liquidated damages 4•1 Arrange for the Contractor, with consent of the are speciried in the Construction Contract, actual dam- Owner, to perform and complete the Construction ages caused by delayed performance or non-perfor- Contract; or mance of the Contraccor. 4•2 Undertake to perform and complete the Construc- � The Surery shall not be liable to the O�vner or others for tion Contract itseif, through its agents or through inde- obligations of the Contractor that are unrelated to the Con- pendent contractors; or struction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such 4.3 Obtain bids or negotiated proposals from unrelated obligations. No right of action shall accrue on qualified contractors acceptable to the Owner for a this Bond to any person or entity other than.the Owner or contract for performance and completion oi the Con- its heirs, executors, administrators or successors. struction Contract, arrange for a contract to be pre- pared for execution by the Owner and the contractor $ The Surety hereby waives notice of any change, includ- selected wich the Owner's concurrence, to be secured �ng changes of time, to the Construction Contract or to with performance and payment bonds executed by a �elated suocontracts, purchase orders and other obliga- qualified surety equivalent to the bonds issued on the tions. Construction Contract, and pay to the Owner the 9 Any proceeding, legal or equitable, under this Bond amount of damages as described in Paragraph 6 in ex- cess of the Balance of the Contract Price incurred by the may be insticuted in any court o(competent jurisdiction in Owner resulting from the Contractor's default; or tne location in which the work or part of the�vork is located and shall be instituted within two y�ars after Contractor 4•� Waive its right to perform and complete, arranoe Default or within two years a(ter the Contractor ceased for completion, or obtain a new contractor and with working or within two years a(ter 1he Surety re(uses or fails reasonable promptness under Ihe circumstances: to perform its obligations under this Bond, whichever oc- curs first. If the provisions of this Paragraph are void or •7 After investigation, determine the amount (or prohibited by law, lhe minimum period of limitalion avail- A�A OOCUMEN7 .v12 • PERFQR,ti1�NCE 80ND AfJU PAYMENT 60N0 • OECEM6ER t98-r ED. • ni�.-,� TF!F .�ntiERIUN INSTITUTE OF .\RCHITECTS, vJS NEW YORX nVE,. ,y�y wqSHINGTON, D.C. 2000G 7HIR0 PRINT�NC • ,�.t,�RCN 7987 �3�2 ��,� 2 able to sure�ies as a defense in the jurisdiction of the suit shall be applicable. tractor of any amounts received or to be received by the Owner in settlement of insurance or other clairr�s 10 Notice to the Surery, the Owner or the Contractor shall Eor damages to which the Contractor is entitled, re- be maiied or delivered to the address shown on the sig- duced by all valid and proper payments made to oron nature page. behalf or the Contractor under the Construction Con- tract. 11 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where 12-2 Construction Contract: The agreement between the�onstruction was to be performed,any provision in this the Owner and the Contractor identified on the sig- Bond conflicting with said statutory or legal requirement nature page, including all Contract Documents and shall be deemed deleted herefrom and provisions con- changes thereto. forming to such statutory or other legal requirement shall 12.3 Contractor Default: Failure of the Contractor, be deemed incorporated herein. 7he intent is that this which has neither been remedied nor waived, to pe�_ Bond shall be construed as a statutory bond and not as a form or otherwise to comply with the terms of the common law bond. Construction Contract. 12 DEF1N1TlONS 12.4 Owner Default: Failure of the Owner,which has 12.7 Balance of the Contract Price: The total amount �either been remedied nor waived, to pay the Con- payable by the Owner to the Contractor under the cractor as required by the Construction Contract or to Construction Contract after all proper adjustments perform and complete or comply with the other terms have been made, including aliowance to the Con- thereof. MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACI'OR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: Address: .11A DOCUhSENT A��2 • PERFORMANCE DONO ANO PAYMENT ppNO • DECEMDER 198a EO. • .\IA � 7HE �.MERIUN INSTITUTF OF ,�RCNITECTS, 17J5 NE�' YORK AVE„ N,y�, y�ASHING70N, O.C. 2000G Tr�IAD PRIN7ING • M�RCH �987 A3�2_1gB4 3 THE AMERICAN INSTITUTE OF ARCHITECTS Bond /: 111 1928 2447 AIA Document A312 Payment Bond Any singular reference to Contractor, Surety, Owner or other party shali be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business): Penzel Construction Company, Inc. The American Inaurance Company 777 San Harin Drive P.O.Boa 330 Novato, California 94998 (314) 569-7300 .Tackson, Missouri 63755 OWNER (Name and Address): City of Cape Girardeau City Hall P.O. Boa 617 Cape Girardeau, MO 63702 CONSTRUCTION CONTRACT �ate: ��1993 Af1lOU11t:T�ee dred Ninety Sia Thausand One Hundred Seventy Five And 45/100 Dollars( S396,175.45) Description (Name and Location):FAA AIP No. 3-29-0013-04 Entrance Road Improvements to Cape Girardeau Hunicipal Airport BOND Date (Not earlier than Construction Contract Date): � a�,/99.� Amount:�� ndred Ninet7 Six Thvusand One Hundrei Se�eat7 Pi�e 45/1��1�llars( S396,175.45) Modifications to this Bond: � None ❑ See Rage 6 CONTRACTOR AS PRINC:P41. SURETY Company: (Carporate Seal) Company: (Cc:porate Seal) Penzel Constr»ct:ton Company, 7.nc. The American Insurance Company •F � - ; - � • ; � � , _y ..__ ` ��-�.'�--' ' . . .. Signature: ___ '' � s Signature: Name and Title Garl u. �enzel, President Name and Title Melissa D. Evans Attozney-In-Fact (Any additional �'sg�7�tures appe�r on page 6) (FOR lNFORMAT/ON ONLY - Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or other party): Lockton Insurance Agency P.O. Boz 8418 Prairie Village, RS 66208 AIA DOCUMENT A312 • PERFORMANCE BOND AND PAYMENT BOND - DECEMBER 1984 ED. - AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 P312-7984 4 1 The Contractor and che Surety, jointly and s?verally, 6 ��/hen the Claimanc has satis�ieC cre conditions �� bind tnemselves, �heir heirs, exec�tors, adminiscrators, Paragraph -t, �he Surety snall prcmpcly and at the successors and assigns to the Owner to pay �or labor, Surery's expense take che �ollowing acc�ons: materials and equipment furnis'r.ed for use in che perror- marce of the Conscruction Contrac[, which is incorpo- 6•i Serd an answer ;o the Claimant, with a copy ,o raced herein oy reference. the Owner, within 45 days after receip[ o� :he claim scating the amounts that are undisputed and the basis 2 With respect to the Owner, �his obligation shail be for chalierging any amounts thac are dispu�ed. null and void if the Contractor: 6.2 Pay or arrange for payment of any �ndisputed 2.� Prompcly makes payment, directly or indirectly, amounts. for all sums due Claimants, and 7 The Surety's total ooligation shall not exceed the 2-2 DeTends, indemnifies and holds harmless the amount or chis Bond, and the amount of this Bond shall be Owner from claims, demands, liens or suits by any credited �or any paymencs made in gcod �aith by the Surery. person or entity whose claim, demand, lien or suit is ror the payment ror labor, materials or equipment`ur- 8 Amounts owed by the Owner to che Contractor under nished for use in the perrormance of the Construction the Construction Contract shall be used for the perfor- Contract, provided the Owner has promptly notified mance of the Construction Contrac; and to satisfy claims, the Contractor and the Surety (at the address if any, under any Construction Perormance Bond. By described in Paragraph 12) o� any claims, �'emands, the Contractor furnishing and the Owner accepting this liens or suits and tendered defense or such claims, Bond, they agree that all funds earned by the Contractor demands, liens or suits to the Contractor and the in the performance of the Construction Contract are Sure,ry, and provided there is no Owner Default. dedicated to satisfy obligations of the Contractor and 3 With respect to Claimants, Lhis obli ation shail be the Surety unde� this Bond, subject to the Owners prior- g ity to use che �unds for che completion of che worlc. null and void if the Contractor promptly makes pay- ment, directly or indirectly, for all sums due. 9 The Surety shall not be liable co the Owner, Claimants 4 The Surety shall have no obligation to Claimants or others for obligacions of the Contractor that are unrelat- under chis Bond until: ed to the Construction Contract. The Owner shall not be liable Tor payment of any cosu or expenses of any Claim- 4.� Claimants who are employed by or have a direct ant under this 8ond, and shall have under this Bond no obli- contract with [he Contractor have given notice to the gations to make paymenu to, give notices on behalf of, or Surety (at the address described in Paragraph �2) and otherwise have obligations co Cizimanu under tnis Bond. sent a copy, or notiCe thereoi, to the Owner, 5tating that a claim is being made under this Bond and, with 10 The Surety hereby waives notice of any change, substantial accuracy, the amount of the claim. including changes of time, to the Construction Contrzct 4•2 Claimants who do not have a direct contract o� to relaced suocontracts, purchase orders and other with the Con[ractor: obligations. .1 Have furnished written notice to the Con- 7� Vo suit or action shall be commenced by a Claimant tractor and sent a copy, or notice thereof, to under this Bond ocher than in a cour oT competent juris- the Owner, within 90 days after having last diction in the location in which the work or part of the performed labor or last furnished materials or work is located or after the expiration of one year from the equipment inciuded in the claim stating, with date(l)on which the Claimant gave the notice required by substantial accuracy, the amount of the claim Subparagraph 4.1 or Clause 4.23, or (2) on which the last and the name of the party to whom the labor or service was performed by anyone or the last mate- materials were �urnished or supplied or for rials or equipment were furnished by anyone under the Con- whom [he labor was done or performed; and struction Contract, whichever of(�)or(2) first occurs. If the •- - - provisions or this Paragraph are void or prohibited by law, .2 Have either received a rejection in whole or the minimum period of limitation available to sureties as a in part from the Contractor, or not received de�ense in [he jurisdiction of che suit shall be applicable. within 30 days of furnishing the above no- tice any communication from the Contractor by which �he Contractor has indicated the �2 Nocice to the Surety, the Owner or the Contractor claim will be paid directly or indirectly; and shall be mailed or delivered to the address shown on the signature page. Actual receipt o� notice by Surety, the .3 Not having been paid within the above 30 Owner or the Contractor, however accomplished, shall days, have sent a written notice to the Surery be sufficient compiiance as of che date received at the (at the address described in Paragraph�2)and address shown on the signature page. sent a copy, or notice chereof, to the Owner, stating that a claim is being made under this 13 When this Bond has been furnished to comply with a Bond and enclosing a copy of che previous statutory or other legal requirement in the location where writcen notice furnished to the Contractor, the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement 5 If a notice required by Paragraph 4 is given by the shall be deemed deleted herefrom and provisions con- Owner to the Contractor or to the Surety, chac is suffi- forming co such statutory or other legal requirement shall cient compliance. be deemed incorporated herein. The intenc is that this .�in DOCU�tF,tiT AJ�z • PERFOR.�tnNCE OOND nNO PnYnaENT BOND• OECEMDER 798-� ED. - �.1�9 THE n,�.tERIC�,� i,tiSTi7UTE OF hRCHITECTS, 17)5 NEW YORK hVE„N.W.,W/�SHINGTCN, D.C. ?CL"�G THIRD PRIN7INC � n1.�RC}i 198� t�312-i90� 5 Bond shall be construed as a statutory bond and not as a Construction Contract, architectural and engineering common law bond. services required for perrormance of the worfc of the l4 Upon request by any person or entity appearing to be a Contractor and the Contractor's subcontractors, and potential beneficiary of this Bond, the Contractor shall all other items for which a mechanic's .lien may be promptly furnish a copy of this Bond or shall permit a copy asserted in the jurisdiction where the labor, materials to be made. or equipment were furnished. 15 DEF1NlT]ONS 15•2 Construction Contract:The agreement becween the Owner and the Contractor identified on the sig- 15.1 Claimant: An individual or entity having a direct nature page, including all Contrac-[ Documents and contract with the Contractor orwith a subcontractor of changes thereto. the Contractor to furnish labor, materials or equip- ment for use in the performance of the Contract. The �5.3 Owner Default: Failure of the Owner,which has intent of this Bond shall be to include without limita- neither been remedied nor waived, to pay the Con- tion in the terms "labor, materials or equipment" that tractor as required by the Construction Contract or to part of water, gas, power, light, heat, oil, gasoline, perform and compiete or compiy with the other terms telephone service or rental equipment used in the thereof. MODIFICATIONS 70 TH[5 BOND ARF AS FOLLOWS: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRAC"i'OR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: Address: AIA DOCUMEf�lT A312 • PERFORM.\NCE BOND AND PAYMENT BONO • DECEMBER 1�8-f ED. • /��n � THE /.MERIUN INST17U7E OF r�RCHITEClS, 17]5 NEW YORK AVE., N.W., W/�SHINGTON, D.C. 2000G TH1RD PkINTInrG • M.�RCH 1987 A372-1984 6 r GENERAI. POWER OF ATI'ORNEY THE AMERICAN INSURANCE COMPANY KyOW ALL MEN BY THESE PRESENTS: That THE A�tERICAN INSURANCE COMPANY,a Corpora�ion incorporared under the laws of the State of New Je:sey on February 20, I8�16,and redomesticated to the State of Nebraska on June 1, 1990,and having its principal of�ce in the City of Omaha,State of Nebraska,has made,constituted and appointed,and does by these presents make,constitute and appoint .7��ES C. PATEIDL, MI CHAEL D. WFiIPPS, JANET ?. RF.HK�P, BARRAR� �1. uEEv, .�LI�SA D. EJANS, TRUDI A. STURESUND, PATRZCK T. PRIBYL aiid DGUGLAS r. IR�'Iid, jo�ntly or severally PRAInIE �ILLAGE, KS iu true and lawful Attorney(s)-in-Fact,with full power and authority hereby conferred in its name,place and stead,to execute,seal,acknowledge and deliver any and all bonds,undertaking,recognizances or other written obligations in the nature thereof ------------------------------------- and to bind the Corporation thereby as fully and to the same extent as if such bonds were signed by the Prosident, sealed with the corporate seal of the Corporation and duly attested by its Secretary,hereby ratifying and confirming all that the said Attorney(s)-in-Fact may do in the premises. This power of attomey is granted pursuant to Article VII,Sections 45 and 46 of By-laws of THE AMERICAN INSURANCE COMPANY now in full force and cffcct. "Artide VII.Appointment and Aut6ority of Resident Secretaries,Attorneys-in-Fact and Agents to accept Legal Procr�s snd Ma1ce Appearnnces. Section 45.Appointmeat. The Chairman of the Board of Directors, the President, any Vico-President or xny other person xuthorized by the Board of Directors,the C6airman of the Board of Directors,the President or any Vice-President may,from time to time,appoint Resident Assistant Secretaries and Attorneys-iu-Fact to represent and act for and on behalf of the Corporsdon and Agenu to accept legai process and make appearances for and on behalf of the Corpontion. Section 46.Authorily.The authority of such Resident Assistant Secretaries,Attorneys-in-Fact and Agents shall be as prescribed in the instrument evidencing their appointment.Any such appointment and all authority granted thereby may be revoked at any time by the Board of Directors or by any person empowered to malce such appointment:' This power of attorney is signed and sealed under and by the authoriry of the following Resoludon adopted by the Board of Directors of THE AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 31st day of July,1984,and said Resolution has not been amended or repealed: "RESOLVED, that the signature of any Vice-President, Assistant Secrecary, and Resident Assistant Secretary of this Corporation, and the seal of this Corporation may be affixed or printed on any power of attorney,on any revocation of any power of attorney,or on any certificate relating thereto,by facsimile, and any power of attorney,any revocation of any power of attorney,or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Corporation:' IN WITNESS WHEREOF,THE AMERICAN INSURANCE COMPANY has caused these presents to be signed by its Vice-President,and its corporate seal to be hereunto affixed this 2 9 t h day of Ma c h —, 19�_. =E"�p:;�'', THE AMERICAN INSURANCE COMPANY ��yf p ,'=J' ��' D� VICG-pTtSIdCII[ ,�L9�NCE�C��Qf STATE OF CALIFORNIA �. COUNTY OF MARIN Onthis 29th dayof �rch 19 93 ,beforemcpersonallycame R. D. Farnsworth to me known,who,being by me duly swom,did depose and say:that he is Vice-President of THE AMERICAN INSURANCE COMPANY,the Corporation described in and which executed the above instrument;that he knows the seal of said Corporation;that the seal afFixed to the said iastrument is such corporate seal;thac it was so affixed by order of the Boazd of Directors of said Corporation and that he signed his name thereto by like order. IN WITNESS WHEREOF,I have hereunto set my hand and affixed my official seal,the day and year hercin first above written. . �� r1::�v �. C�F!c;;,��r.OT.ar`',Y SE�� ' —5�;� a. �cR:��FA ':=.t- t� .r3:;=x•:, Notary�ut:x—.C,a�i."xnia No� � ""'� ' cr„+vc:i�.�U;a i I .� '�� hSy�.am- >=zp. ivWR 20.15�5 CERT'IFICATE ''`�:'. s�r STATE OF CALIFORNIA �, COUNTY OF MARIN I,the undersigned,Raident Assistant Sccretary of THE AMERICAN INSURANCE COMPANY,a NEBRASKA Corporation,DO HEREBY CERTIFY that the foregoing and attached POWER OF AZ'I'ORNEY recaains in full force and has not been revoked;aod furthermore that Article VII,Sections 45 and 46 of the By-laws of the Corporation,and the Resolution of the Boazd of Directors;set fonh in the Power of Attomcy,are now in force. Signed and sealed at the County of Marin.Dated the day of , 19 • �'"";:%c�, ,�4 r .�y'�, � 'I';E _ qJ��f Raidmc w..:..+..t Socreury < L��M[E��f 360712-TA-6-90(REV) � ! CHANGE ORDER N0. 2 Date Prepared March 17, 1994 PROJECT: Entrance Road Improvements AIP No. 3-29-0013-04 OWNER: Cape Girardeau Municipal Airport P.O. Box 617 Cape Girardeau, MO 63702 ENGINEER: Crawford, Murphy & Tilly, Inc . 133 South llth Street, Suite 500 St .Louis, Mo 63102 CONTRACTOR: Penzel Construction Company, Inc . P.O. Box 330 Jackson, Mo 63755 Requested changes and reasons for changes : Item SP. NO. 12 .4 ADDITIONAL PARKING LOT LIGHTING Add 1 LLTMP SLTM @ $7, 500 . 00 (+) $7, 500 . 00 Reason For Change : The City of Cape Girardeau has requested that 2 additional light poles with 2 fixtures per pole be installed in the center of the terminal parking area to eliminate some dark areas which could pose a safety hazard. This lump sum fee includes all wiring, trenching, pavement removal, concrete work, etc . incidental to the installation of the poles and fixtures . The steel poles and metal halide light fixtures shall be the same equipment as supplied for the original contract items SP.NO. 3 . 3 and SP.NO. 3 . 1 respectfully. The $1, 635 . 00 that this lump sum price is above the as-bid contract price for the individual items involved represents compensation to the contractor for remobilization of a drill rig, crane, and trencher. Also included are some material price increases . 1 1 of 3 � . � , SUN�iARY C.O. No.2 Total Additions C.O. No. l (+) $ 7, 500 . 00 Total Deductions C.O. No. 1 (-) $ 0 . 00 Total Net Change C.O. No. 1 (+) $ 7, 500 . 00 PROJECT COST SUMMARY As-Bid Contract Amount $396, 175 .45 Previous Change Orders $ 16, 126 . 38 Change Order No. 2 $ 7, 500 . 00 New Contract Amount $419, 801 . 83 � 2 of 3 � Change Order No. 2 FAA AIP No. 3-29-0013-04 This Change Order, when executed, constitutes a modification to the Contract and all provisions of the Contract, except as modified above and by any previous Change Orders, shall apply hereto. RECOMMENDED FOR ACCEPTANCE : CRAWFOR MURPHY TIL Y, IN BY: 6"'� ,�` DATE : �- �G' � �`� APPROVED: CITY OF C E GIRARD A , MI OURI BY: ' �� DAT �'Z 2 - �� ACCEPTED: PENZEL CONSTRUCTION COMPANY, INC. BY: ��--c%�"�— l�J ' �Lf DATE : ��f�� h Page 3 of 4 � CHANGE ORDER NO. 3 Date Prepared April 26, 1994 PROJECT: Entrance Road Improvements AIP No. 3-29-0013-04 OWNER: Cape Girardeau Municipal Airport P.O. Box 617 Cape Girardeau, MO 63702 ENGINE$R: Crawford, Murphy & Tilly, Inc. 133 South llth Street, Suite 500 St .Louis, Mo 63102 � - CONTRACTOR: Penzel Construction Company� Inc. P.O. Box 330 - Jackson, Mo 63755 Requested changes and reasons for changes : Item D-701-5.1 12" Dia. Reinforced Concrete Pipe, Class IV Add 20 LF � $18 . 50/LF (+) $370 . 00 Reason For Change : The City of Cape Girardeau has requested this additional piping and shoulder widening (see exhibit #1) to facilitate entry of emergency vehicles to the north end of the airfield. The existing turning radius is very tight and results in the rear wheels of emergency vehicles dropping off in the drainage ditch which runs along the west side of the airport access road. Item P-304-5 .1 Crushed AQqreaate Base Course Add 30 Tons � $16 . 00/Ton (+) $480 . 00 Reason For Change : This material will be used to construct the stabilized shoulder widening. 1 of 3 Item P-403-6 .1 Bituminous Surface Course Add 3 Tons � $43 . 00/Ton (+) $129 . 00 Reason For Change : This material will provide a 2" asphalt wearing course for the stabilized shoulder. Item SP. NO. 12 . 5 Directional Sicins Add 1 Lump Sum Q $154 .28/LS (+) $154 . 28 Reason For Change: These signs have been requested by the City of Cape to inform airport users of the locations of the various airport facilities (see attached letter from Mr.Randy Holdman, Airport Managera . These signs would be constructed of 0 . 090 aluminum wi�h vinyl letters, they will be 24" wide x 18" high. - The signs will be mounted on the new ornamental iron fence by the airport personnel . SUI�SARY C.O. No.3 Total Additions C.O. No.3 (+) $ 1, 133 .28 Total Deductions C.O. No.3 (-) $ 0 . 00 Total Net Change C.O. No.3 (+) $ 1, 133 .28 PROJECT COST SUbIl�iARY As-Bid Contract Amount $396, 175 .45 Previous Change Orders $ 23 , 626 .38 Change Order No. 3 $ 1, 133 . 28 New Contract Amount $420, 935 . 11 2 of 3 Change Order No.3 FAA AIP No. 3-29-0013-04 This Change Order, when executed, constitutes a modification to the Contract and all provisions of the Contract, except as modified above and by any previous Change Orders, shall apply hereto. RECOMMENDED FOR ACCEPTANCE: CRAWFO�MURPHY & TILLY, INC. J BY: � �' � 1 GZ�r� DATE• ¢ — Z La - � �- , 4� APPROVED: CITY OF CAPE GIRARDEAU, MISSOURI sY: � � ��9�� ` DATE• 5'3'�`rt ACCEPTED: PENZE ONSTRUCTION COMPANY, INC. BY- DATE• S"�' \� Page 3 of 3 --� �?E� -� . i, ,� _ � {� ,�oJ�-r 3 Z 9 -O O/3 - o ¢ P`-�-�' s� T .� � � ��- ��,4.` ��7-io,�J �� /�Po S c� �'. 4_ � . 3 . . - . � _ --- • 4 �. .. ,r.{.s..t . ` • — HANGAR N0. � 3 �� - � . • : . " _ � � . � ' - --_ � � _ - - - - - - - - - - - -- - - - - - - � � . ` � PROPOSED 26' W. CAIYTILEyFIq GqTE ' )R PROPOSFD G4RD READER (10' I�R01�,/ G,qTE- I � � . � � � ' � PROPOSED 4' N/GH CKAlN UIYK FENCE -_._ x — x X ay is''� P,�� . `''LT P2oPas�� aG/�C'C�q-r�� _ 2" �,�M� � �co�t w/7i�f — .� _., 0?-1 S., -�,,a — — — — — — '-�`� G°��-- . — - - - - - - -- -• - - - --- - .. P'�p's� /O�SE�r.o� 0� /L"'� PPE �Ty,� �,,�� x�sT �iRPattT AccEss ,G�o�2� "' _ —. - - - - - - - - - - - - - - - - - - _. - - - - - . 11 12 . . � 13 4 . . . � . , �� ..:.►. .,r�� ...�Yy.,,f,:♦ � •� � . . .. ,.r}�, i� f 'J 7;LMl:/ . ,. . . 4�� ,?.�.T .�r r�� Y,fi \ �,t'.l.L'.,.�� . '� •fl��"" ��....�..v_.a.�a.- C7�1� ?�i�{:�. "':�. ` �� ' ? ,�,�;� �t:. �' . � �.�:��.. ��M ��• -I'1� �� t � _ , ° .� '.o.�ox h� A1h►Oi1T WNA�ER !�� - . CAF�OMA/1p�µ�,yG�T70Q�O�iI T�Li1'NONt dt��qNR�O Mx ptq asarM April )4, 1994 . ;�Q��'� .a ,�� :�� . � � �?�s� Mr. Ron Ma�ingly �'�� 4 �� R i Crawford, Murphy & Ti11 1 sp�n �,,�;�,� -'� 9n,� .::%`� 133 South 11 th Sfreet y' nc. . � ��shf��- �� . -�;,;J Suite b00 _ � < ,�� ,,�`�. St. Louls, MO 63102 - 3ZO� �� Dear Ron: As you requested, below is a 'clean" copy of signage for the gate keypads, 7fie #irst grouping should go by the restaurant, the seconc! by Cape Cen�ai. T Ai�iir�es E— Atr��r�es T ACa Ren�a�isratlons E— �Alrport Operations --� Fuel Ssfes �' �Rent�ls T Gift Shop . � Fuel 8ales� 7 Lounge ajft Shop T P�ones � ��a � Rest Rooms <-- Rest Rooms T Restaurant � F- F�estaurani Again, t t�ink i" whl#a fettering on a bronze or brownish background would be appropr(ate. Thanksl Sineerely, �• Randy Nol msn Alrport Mana�er RH/sb CHANGE ORDER NO. 4 . Date Prepared May 20, 1994 PROJECT: Entrance Road Improvements AIP No. 3-29-0013-04 OWNER: Cape Girardeau Municipal Airport P.O. Box 617 Cape Girardeau, MO 63702 ENGINEER: Crawford, Murphy & Tilly, Inc . 133 South llth Street, Suite 500 St .Louis, Mo 63102 CONTRACTOR: Penzel Construction Company, Inc. P.O. Box 330 Jackson, Mo 63755 Requested changes and reasons for changes : Item P-101-5.1 Asphalt Pavement Removal � Add 69 SY � $7. 00/SY (+) $483 . 00 Reason For Change : Additional pavement was removed on the east side of the parking lot at station 2+75, this pavement was in very poor condition due to poor subgrade. Item P-101-5.6 Parking Block Removal Deduct 221 EA Q $5 . 00/EA (-) $1, 105 . 00 Reason For Change : The city picked up these blocks themselves . Item P-304-5 .1 Crushed AQqreQate Base Course Deduct 5 . 20 Tons @ $16 . 00/Ton (-) $ 83 .20 Reason For Change : This represents the final as-built quanity. 1 of 5 Item P-403-6 .1 Bituminous Surface Course ' Add 160 Tons Q $43 . 00/Ton (+) $6, 880 . 00 Reason For Change : Additional asphalt was required on the eastern 2/3 of the parking lot to correct some existing drainage problems . Also in this same area the asphalt was laid 1/2" to 1" thicker than the plan 1-1/2" overlay to provide adequate pavement structure over the poor quality existing asphalt pavement . Item P-301-6.1 Bituminous Base Course Deduct 51. 20 Tons Q $38 . 50/Ton (-) $1, 971 . 20 Reason For Change: This represents the final as-built quanity. Item P-602-5.1 Bituminous Prime Coat Deduct 250 Gal Q $1. 50/Gal (-) $375 . 00 Reason For Change: This represents the final as-built quantity. Item P-603-5.1 Bituminous Tack Coat Add 179 Gal @ $1.50/Gal (+) $268 . 50 Reason For Change : This represents the final as-built quantity. Item D-752-5.2 Cleanout Deduct 1 EA Q $300 . 00/EA (-) $300 . 00 Reason For Change: Only one cleanout was indicated on the plans for installation. Item T-901-5 .1 Seedinq Add 0 . 35 AC C� $2, 000 . 00/AC (+) $700 . 00 Reason For Change : This represents the final as-built quantity. 2 of 5 Item T-908-5 .1 MulchinQ • . Add 0 . 35 AC Q $1, 500 . 00/AC (+) $525 . 00 Reason For Change: This represents the final as-built quantity. Item L-108-5 .1 Cable Trench Deduct 411 LF @ $1 . 05/LF (-) $431 . 55 Reason For Change : Final as-built quantity. One reason less cable and trench was required is that power for the 36' wide cantilever gate was obtained from an existing power pole 264' closer to the gate than was originally shown. - Item L-108-5 .2 2-1/C #4 IISE #8 GND. In Unit Duct Deduct 264 LF Q $1.90/LF (-) $501. 60 Reason For Change: Power for the 36' wide cantilever gate was obtained from an existing power pole 264' closer to the gate than was originally shown. Item L-108-5.3 2-1/C #8 IISE #8 GND. In Unit Duct Deduct 140 LF Q $1 .40/LF (-) $196 . 00 Reason For Change: This represents a final as-built quantity. Item SP.NO. 9 .1 Chrusher Run Material Add 17 .59 TONS @ $11.00/TON (+) $193 .49 Reason For Change: This material was used to stabilize poor subgrade soils at station 2+75 . Item SP. NO. 10 .4 2 Inch Water Main Deduct 55 LF Q $6 . 20/LF (-) $341 . 00 Reason For Change : This represents a final as-built quantity. 3 of 5 SUI�lARY C.O. No.4 Total Additions C.O. No.4 (+) $ 9, 049 . 99 Total Deductions C.O. No.4 (-) $ 5, 304 . 50 Total Net Change C.O. No.4 (+) $ 3 , 745 .44 PROJECT COST STJrIlKARY As-Bid Contract Amount $396, 175 .45 � Previous Change Orders $ 24, 759 . 66 Change Order No. 4 $ 3, 745 .44 New Contract Amount $424, 680 .55 4 of 5 Change Order No.4 FAA AIP No. 3-29-0013-04 ' This Change Order, when executed, constitutes a modification to the Contract and all provisions of the Contract, except as modified above and by any previous Change Orders, shall apply hereto. RECOMMENDED FOR ACCEPTANCE: CR.AWFORD, MURPHY & TILLY, INC. BY: �o'Y` i° � ( DATE: S- �iU � � � APPROVED: CITY OF GI URI BY: DA � '"]v7�� ACCEPTED: PENZE ONSTRUCTION COMPANY, INC. BY: , DATE: 5��3�� 5 of 5 BID TABULATIONS FOR CAPE f31RAR0EAU MUNICIPAI AIRPORT FAA A.I.P PROJECT NO.3-29-OOY3-04 ENTRANCE ROAD IMPROVEMENTS ENGIN@ER'S ESTfMATE PENZEL CONSTRUGTION GAEGORY CONSTRUCTION UNIT TOTAL UNIT TOTAL UNiT TOTAL ITEM N0. DE5CAIPTION pUANTIlY COST COST COST COST COST COST P-107-5.1 ASPNALT PAVEMENT REMOVAL 2,926 SY S3.06 S$,7?6.00 $7.00 $20,482.00 $6.B0 $19,311.60 P-101-5,2 CONCFETE PAVEMENT REMOVAI 547 SY 10.00 5,410.00 13.50 7,303.50 7,75 4,192.75 P•101-5,3 COLD PIANING 62t SY 20.00 12,420.00 4,00 2,484.0� f0.75 8,675.75 P-101-5.4 4'HIGH GNAIN•IiNK FENCE REMOVAL 601 LF 2.00 1202.00 5.00 3,005.00 2.81 1,688.81 P-101-5.5 7`HIGH CHAIN•LINK FENCE REMOVAL 370 LF 4.00 1,480.00 7.00 2,590.00 3.27 1,209.90 P-101-5.8 PARKING BLOCK REMdVAL 226 EA 10.00 2,280.00 5.00 1,134.00 6.00 1,356.00 P-152-4.1 UNCtASSIFIED IXCAVATION 366 CY 10.00 3,660.00 10,00 3,660.00 11,00 4,028.00 P-304•5.1 CRUSHEO AGGREGATE E3ASE COURSE 166 TON 12.00 1,992.00 16,00 2,656.00 16.00 2,656.00 P-403-6.1 BITUMINOUS SURFACE COtJASE 1,249 70N 40.OQ 49,960.00 43.00 53,767.00 44.06 55,055.92 P�301-6.1 BITUMINOUS BASE COURSE 454 TON 35.00 15,890.00 38.50 17,479.00 39.78 18,060.12 P-602-5.1 BITUMINOUS PRIME COAT 530 GAL 2.00 1,060.00 1.50 795.00 1.61 853,30 P-803-5.1 BITUMINOUS TACK COAT B01 GAL 2.00 t,202.00 1,50 901.5d 1.61 967.61 D-701-5.1 12"RCP,CLASS IV 505 LF 22.00 11,110.00 18.50 9,342.50 21.50 10,857.50 D-701-5.2 12'PVC PIPE 220 Lf 18.00 3,960.00 73.d0 2,860.00 24.00 5,280.00 D-752-5.1 1z'FLARED END SECTION 14 EA 500.00 7,000.00 245.00 3,430.00 375.00 5,250.00 D-752-5.2 CLEANOUT 2 F1� SOQ.00 1,000.00 300,00 600.00 440.00 880.00 F-162-5.1 4 FOOT HIGH CHAIN-LINK FENCE 490 Lf 15.00 7,350.00 920 4,508.00 9.68 4,743.20 F-182-5.2 26'WIDE DRIVEWAY GATE,ACTUATED 1 EA 'IO,OOO.OD 10,000.00 15,DOD.00 15,000.00 1A,20i.40 14,201.40 F•162-5.3 36'IMIDE DRIVEWAY GATE,ACTUATED 1 EA 15,000.00 15,000.00 23,000.00 23,000.00 22,261,3H 22,281.39 T-901-5.1 SEEDING 0.5 AC 1,280.00 640.00 2,000.00 1,000.00 2,000.00 1,000.00 T-905-5.1 TOPSOILING 440 CY 10.0� 4,400.00 18.00 7,920.00 16.05 7,0&2.00 T-908-5.1 MULCHING 0.5 AC 970.00 485.00 f,500.00 750.d0 2,000.00 1,000.00 L•108-5.1 CABLE TRENCH 3,263 LF 2.10 8,852.30 1.05 3,428.15 Y.13 3,687.19 L-168-5.2 2-1/C#4 USE#8 GND.IN U,Q. 2,084 lF 2.60 5,418.40 t.90 3,959.60 1.94 4,042.98 L-108.5.3 2•t(C#t8 USE#8 GN�.IN U.D. 1,505 lF 2.45 3,687.25 1.40 2,707.00 1,51 2,272.55 L-108-5.4 ELECTRIC HRNOHOLES 2 E4 1,SOO.Od 3,000.00 1,400.00 2,800.00 1,410.40 2,820.80 l•10&5.1 VAULT INSTALLATION 1 LS 5,000.00 5,000.00 1,500.00 1,500.Oa 1,414.70 1,414.70 L-tt45.1 4"PVC C�NCflETE ENCASEO OUCT 326 LF 25.00 8,150.00 19,50 6,35�.00 20.43 6,660.18 SP.N0.1.1 EN�INEER�S F�ELD OFFICE � 2,000.00 2,000.00 �,5oa.oa i,5oo.00 2,aoo,00 2,000.00 SF.N0.2,1 TYPE S CURB 1,?.82 LF 20A0 25,640.00 22.00 28,204.00 16.00 20,5+2,00 SP.NO.22 TYPE 8 CtJRB AN�GUTTER(4'WID 162 LF 18.00 2,916.00 30.80 4,989.60 22.00 3,584.00 SP.N0.2.3 TYPE B CURB AN�Gl1TTER 3'WID 136 LF 15.00 2,040.00 28.70 3,831.20 21.00 2,856.00 SP.N0.2.4 CCNCRETE MECIAN 229 SY 22.00 5,038,00 40.50 9,274.50 27.00 6,183.00 SP.NO.3.1 250 W,METAL HALIDE,240V,LUMINAlRE 27 EA 500.00 13,500.00 450.00 12,150.00 475.15 12,829.05 SP.N0.3.2 CONCRETE LIC3HT POLE 3 F11 1,8D0.00 5,400,00 1,100.00 3,300.00 1,191.10 3,573.30 SP.fJO.3.3 STEEL LIGHT POLE 8 EA 1,800.00 14,400.00 1,500.00 12,000.00 1,639.38 13,115.04 SP.N0.3.d 1NSTALL D(ISTING CdNCAETE POIES 7 EA t,00d.00 7,000.00 370.00 2,590.00 387.00 2,709,00 SP.NO.4.1 INFORMATIONAL SiGN 1 EA 7,800.00 1,eW.0� 2,500.00 2,500.00 2,580.00 2,580.00 SP.N0.5.1 REGULATORY SIGNS 17 EA 250.00 4,250.00 206.00 3,502.00 215.00 3,855.OD SP.N0.6.1 6"DUGTILE IRGN SEWER PIPE 100 LF 32.00 3,200.00 20..00 2,400.00 2Q.00 2,000.40 SP.NO.7.1 ORNAMEN7AL IRON FENCE,7 FT.HI�H 327 LF 32.00 10,464.00 t00.00 32,700.00 178.25 38,667.75 SP.N0.7.2 6'WIDE ORNAMENTAL IRON WALK GATE 3 FJ� 1,000.00 3,OOQ.00 7Q0.00 2,i00.00 967.50 2,902.50 SP.NO.8.1 POST ANO P.'rNEL SfGN 5 EA 600.00 ?�r?(i.:)0 1,030.00 5,150.00 1,075.00 5,375.00 5P.NO.4.1 CAUSHER RUN MATERIAL 58U TON 12.00 E,S60::0 11.00 6,380.00 15.00 8,700.D0 SP.NO.8.2 GEOSYNTHETIC FABRIC 755 5Y 2.00 1,510.00 1.50 t,132.50 2.75 2,076.25 SP.Na.10.1 12 INCH WATER MAIN 880 LF 21.00 18,480.00 26.60 23,408,00 21.80 19,008.00 5?.NO.10.2 61NCH WATER MAIN 220 lF 10.00 2,200.00 18,50 4,070.00 19.75 4,345.00 SP.F10.10.3 4 INCH WATER MAIN 820 LF 8.00 6,560.00 t2.30 10,086.00 B.OD 4,920.�0 SP.NO.10.4 2 INCH WATEfl MAIN 80 LF 8.00 480.00 8.20 498.00 8.00 640.00 SP.NO.70.5 FIRE HYDRANTS 5 EA 1,200.00 6,000.00 1,100.00 5,500.00 1,545.00 7,725.00 SP.NO.10.6 6 INCH GATE VA�VE 6 EA 550.00 3,300.00 330.00 1,980.00 540.00 3,240,00 SP.NO.1Q.7 FITTINGS 1 LS 4,500.00 4,500.00 2,4p0.00 2,400.00 26,801.20 28,801.26 SP.U0. 10,8 GAANULARBACKFILL 275 CY 20.00 5,500.00 �5.00 4,125,00 22.00 6,OSD.00 SP.NO. tt.t PAVEMENTMARKING 1,926 LF 1.50 2,B80.60 0.52 998.44 O.fi7 1,286.40 SP.N0.12.1 BRADFORD CALLERY PEAR 3 EA 22o.oa 660.0o si.0o 183.00 131.15 3s3.a5 SP.NO.12.2 R081NSON CRABAPPLE 4 EA 220.00 880.00 61.00 244.00 183.40 653.80 SP.NO.t2.3 SEBIAN YEW 108 EA 6Q.00 6,480.00 41.00 4,428.00 65.58 7.082.64 TOTAI 5368,404.93 TOTAL $396,175.43 TOTAL 5428,930.81 U7ILITY RELC:�ATIONS AND SERVECE 55,000.00 28-Jul•93 GRAND TOTAL 5373,404.95