Loading...
HomeMy WebLinkAboutRES.2442.04-06-2009BILL NO. 09-62 A RESOLUTION AUTHORIZING MANAGER TO EXECUTE AN ZOELLNER CONSTRUCTION RENOVATIONS TO THE A BUILDING, IN THE CITY O MISSOURI. RESOLUTION NO.7 THE INTERIM CITY AGREEMENT WITH O., INC., FOR _. BRASE ARENA CAPE GIRARDEAU, BE IT RESOLVED BY THE COUNCIL OF THE CITY OF CAPE GIRARDEAU, MISSOURI, AS FOLLOWS: ARTICLE 1. The Interim City Manager, for and on behalf of the City of Cape Girardeau, Missouri, is hereby authorized to execute an Agreement with Zoellner Construction Co., Inc., for renovations to the A.C. Brase Arena Building, in the City of Cape Girardeau, Missouri. A copy of said Agreement is attached to this Resolution and made a part hereof. PASSED AND ADOPTED THIS 7 DAY OF 20.'�� �4�gDEAijl� J B . Knudtson, Mayor � O v `ll� onrad,; City Clerk i CITY OF CAPE GIRARDEAU Department of Parks and Recreations A. C. Brase Arena Renovations 410 Kiwanis Drive Cape Girardeau, Missouri STANDARD FORM OF AGREEMENT BETWEEN OWNER AND CONTRACTOR ON THE BASIS OF A STIPULATED PRICE THIS AGREEMENT is dated as of the 944A day of Agn 1 in the year 2009 by and between the City of Cape Girardeau, Missouri (hereinafter called OWNER) and Zoellner Construction Co., Inc. (hereinafter called CONTRACTOR). OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows: Article 1. WORK. CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: Renovations to A. C. Brase Arena building located at 410 Kiwanis Drive. Building addition, roof replacement, exterior wall improvements, HVAC replacement, electrical upgrade, emergency generator. Article 2. ENGINEER. The City Engineer or his designee is to act as OWNER'S representative, assume all duties and responsibilities and have the rights and authority assigned to ENGINEER in the Contract Documents in connection with completion of the Work in accordance with the Contract Documents. Article 3. CONTRACT TIMES. 3.1 The work will be substantially completed by August 21, 2009 after the date when the Contract Times commence to run as provided in paragraph 2.3 of the General Conditions, and completed and ready for final payment in accordance with paragraph 14.13 of the General Conditions by August 28, 2009 after the date when the Contract Times commence to run. A-1 3.2 Liquidated Damages. OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not completed within the times specified in paragraph 3.1 above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. They also recognize the delays, expense and difficulties involved in proving the actual loss suffered by OWNER if the Work is not competed on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as liquidated damages for delay (but not as a penalty) CONTRACTOR shall pay OWNER five hundred dollars — ($500) for each day that expires after the time specified in paragraph 3.1 for Substantial Completion until the Work is substantially complete. After Substantial Completion, if CONTRACTOR shall neglect, refuse or fail to complete the remaining Work within the time specified in paragraph 3.1 for completion and readiness for final payment or any proper extension thereof granted by OWNER, CONTRACTOR shall pay OWNER five hundred dollars — 500 for each day that expires after the time specified in paragraph 3.1 for completion and readiness for final payment. Article 4. CONTRACT PRICE. OWNER shall pay CONTRACTOR for completion of the Work in accordance with the Contract Documents an amount in current funds equal to the sum of the amounts determined pursuant to paragraphs 4.1 and 4.2 below: 4.2 for all Unit Price Work, an amount equal to the sum of the established unit price for each separately identified item of Unit Price Work times the estimated quantity of that item as indicated in the bidding documents. LUMP SUM CONTRACT AMOUNT: $1,296,140.00 (Includes Alternates 1-10) (See attached outline for alternates) Article 5. PAYMENT PROCEDURES. CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Applications for Payment will be processed by ENGINEER as provided in the General Conditions. 5.1 Progress payments; Retainage. OWNER shall make progress payments on account of the Contract Price on the basis of CONTRACTOR'S Application for Payment as recommended by ENGINEER, on or about the 10th day of each month during construction as provided in paragraphs 5.1.1 and 5.1.2 below. All such payments will be measured by the schedule of values established in paragraph 2.9 of the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no schedule of values, as provided in the General Requirements. A-2 5.1.1 Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below, but, in each case, less the aggregate of payments previously made and less such amounts as ENGINEER shall determine, or OWNER may withhold, in accordance with paragraph 14.7 of the General Conditions. 90% of Work completed (with the balance being retainage). If Work has been 50% completed as determined by ENGINEER, and if the character and progress of the Work have been satisfactory to OWNER and ENGINEER, OWNER, on recommendation of ENGINEER, may determine that as long as the character and progress of the Work remain satisfactory to them, there will be no additional retainage on account of Work completed, in which case, the remaining progress payments prior to Substantial Completion will be an amount equal to 100% of the Work completed. 90% (with the balance being retainage) of materials and equipment not incorporated in the Work (but delivered, suitably stored and accompanied by documentations satisfactory to OWNER as provided in paragraph 14.2 of the General Conditions). 5.1.2 Upon Substantial Completion, in an amount sufficient to increase total payments to CONTRACTOR to 95% of the Contract Price (with the balance being retainage), less such amounts as ENGINEER shall determine, or OWNER may withhold, in accordance with paragraph 14.7 of the General Conditions. 5.2 Final Payment. Upon final completion and acceptance of the Work in accordance with paragraph 14.13 of the General Conditions, OWNER shall pay the remainder of the Contract Price as recommended by ENGINEER as provided in said paragraph 14.13. Article 6. INTEREST. All moneys not paid when due as provided in Article 14 of the General Conditions shall bear interest at the maximum rate allowed by law at the place of the Project. Article 7. CONTRACTOR'S REPRESENTATIONS. In order to induce OWNER to enter into the Agreement, CONTRACTOR makes the following representations: 7.1 CONTRACTOR has examined and carefully studied the Contract Documents (including the Addenda listed in paragraph 8) and the other related data identified in the Bidding Documents, including "technical data". 7.2 CONTRACTOR has visited the site and become familiar with and is satisfied as to the general, local and site conditions that may affect cost, progress, performance and furnishing of the Work. A-3 Z 7.3 CONTRACTOR is familiar with and is satisfied as to all federal, state and local Laws and Regulations that may affect cost, progress, performance and furnishing of the Work. 7.4 CONTRACTOR has carefully studied all reports of explorations and tests of subsurface conditions at or contiguous to the site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the site (except Underground Facilities) which have been identified in the Supplementary Conditions as provided in paragraph 4.2.1 of the General Conditions. CONTRACTOR accepts the determination set forth in paragraph SC -4.2 of the Supplementary Conditions of the extent of the "technical data" contained in such reports and drawings upon which CONTRACTOR is entitled to rely as provided in paragraph 4.2 of the General conditions. CONTRACTOR acknowledges that such reports and drawings are not Contract Documents and may not be complete for CONTRACTOR'S purposes. CONTRACTOR acknowledges that OWNER and ENGINEER do not assume responsibility for the accuracy or completeness of information and data shown or indicated in the Contract Documents with respect to Underground Facilities at or contiguous to the site. CONTRACTOR has obtained and carefully studied (or assumes responsibility for having done so) all such additional supplementary examinations, investigations, explorations, tests, studies and data concerning conditions (surface, subsurface and Underground Facilities) at or contiguous to the site or otherwise which may affect cost, progress, performance or furnishing of the Work or which relate to any aspect of the means, methods, techniques, sequences and procedures of construction to be employed by CONTRACTOR and safety precautions and programs incident thereto. CONTRACTOR does not consider that any additional examinations, investigations, explorations, tests, studies or data are necessary for the performance and furnishing of the Work at the Contract Price, within the Contract Times and in accordance with the other terms and conditions of the Contract Documents. 7.5 CONTRACTOR is aware of the general nature of work to be performed by OWNER and others at the site that relates to the Work as indicated in the Contract Documents. 7.6 CONTRACTOR has correlated the information known to CONTRACTOR, information and observation obtained from visits to the site, reports and drawings identified in the Contract documents and all additional examinations, investigations, explorations, tests, studies and data with the Contract Documents. 7.7 CONTRACTOR has given ENGINEER written notice of all conflicts, errors, ambiguities or discrepancies that CONTRACTOR has discovered in the Contract Documents and the written resolution thereof by ENGINEER is acceptable to CONTRACTOR, and the Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. I Article 8. CONTRACT DOCUMENTS. The Contract Documents which comprise the entire agreement between OWNER and CONTRACTOR concerning the Work consist of the following: 8.1 This Agreement (pages 1 to 7 inclusive). 8.2 Exhibits to this Agreement. 8.3 Performance, Payment, and other Bonds, identified as exhibits "A" and consisting of pages. 8.4 Notice to Proceed, Dated: 8.5 General Conditions (pages 1 to 55 , inclusive). (EJCDC No. 1910-8 1990 Edition) 8.6 Supplementary Conditions (pages SC- 1 to SC- 7 , inclusive). 8.7 Specifications bearing the title A. C. Brase Arena Renovations, dated February, 2009. 8.8 Drawings. (see attached sheet) Page 1 of 1. 8.9 Addenda numbers 1 of 1 , inclusive. 8.10 CONTRACTOR'S Bid (pages BF- 1 to BF- 8 , inclusive) marked exhibit "B" (including the roofer's qualification information, pages 1 & 2) 8.11 Documentation submitted by CONTRACTOR prior to Notice of Award: Qualification statements for Schneider Electric Co., pages 1 — 25. Bid Bond dated March 17, 2009, pages 1-2. 8.12 The following which may be delivered or issued after the Effective Date of the Agreement and are not attached hereto: All Written Amendments and other documents amending, modifying or supplementing the Contract Documents pursuant to paragraphs 3.5 and 3.6 of the General Conditions. The documents listed in paragraphs 8.2 et seq. above are attached to this Agreement (except as expressly noted otherwise above). There are no Contract Documents other than those listed above in the Article 8. The Contract Documents may only be amended, modified or supplemented as provided in paragraphs 3.5 and 3.6 of the General Conditions. A-5 Article 9. MISCELLANEOUS. 9.1 Terms used in this Agreement which are defined in Article 1 of the General Conditions will have the meanings indicated in the General Conditions. 9.2 No assignment by a party hereto of any rights under or interests in the Contract Documents will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 9.3 OWNER and CONTRACTOR each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, its partners, successors, assigns and legal representatives in respect to all covenants, agreements and obligations contained in the Contract Documents. 9.4 Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon OWNER and CONTRACTOR, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. IN WITNESS WHEREOF, OWNER and CONTRACTOR have signed the Agreement in multiple copies, One counterpart each has been delivered to CONTRACTOR and ENGINEER and two counterparts to the OWNER. All portions of the Contract Documents have been signed, initialed or identified by OWNER and CONTRACTOR or identified by ENGINEER on their behalf. This Agreement will be effective on Rpr o q , 20091 (which is the Effective Date of the Agreement). OWNER City of Cape Girardeau CONTRACTOR-Z6''L�'� 614"�7`�.��-t''� Ken Eftink, Interim City Manager 1416, [CORPOPTE SEAL] Attest {:{� Address for giving notices: sm Attest Address for Department of Parks and Recreation C? % 5 // c r 1 Szz Mr. Daniel Muser, Director 410 Kiwanis Drive Cape Girardeau, MO 63701 (If OWNER is a public body, attach evidence of authority to sign and resolution or other documents authorizing_�jxecut_ion of Agreement. License No. -7 371 Agent for service of process: (If CONTRACTOR is corporation, attach evidence of authority to sign.) 6 _z:� 77' I CITY OF CAPE GIRARDEAU Department of Parks and Recreation A. C. Brase Arena Renovations 410 Kiwanis Drive Cape Girardeau, Missouri SUPPLEMENTARY CONDITIONS EJCDC 1910-17 (1990) These Supplementary Conditions amend or supplement the Standard General Conditions of the Construction Contract (No 1910-8) (1990) and other provisions of the Contract Documents as indicated below. All provisions which are not so amended or supplemented remain in full force and effect. SC -1 The terms used in these Supplementary Conditions have the meanings assigned to them in the General Conditions. SC -1.18 ENGINEER'S Consultants as defined in the General Conditions are: PHILLIP B. SMITH ARCHITECT LLC 332 South Silver Springs Road Cape Girardeau, Missouri. SC -2.2 Amend the first sentence of paragraph 2.2 of the General Conditions to read as follows: "OWNER shall furnish to CONTRACTOR up to six (6) copies of the Contract Documents, as are reasonably necessary for the execution of the work", and as so amended paragraph 2.2 remains in effect. SC -2.7 Delete paragraph 2.7 of the General Conditions in its entirety and insert the following in its place: "CONTRACTOR shall deliver certificates of insurance with the executed Agreement as set forth in paragraph 18. of the Instructions to Bidders. SC -5.3.2 Amend paragraph 5.3.2 of the General Conditions by deleting the second sentence in its entirety. SC -5.4.1 Workers' Compensation and Employers' Liability Insurance. This insurance shall protect Contractor against all claims under applicable state workers' compensation laws, including coverage as necessary for the benefits provided under the United States Longshoremen's and Harbor Workers' Act and the Jones Act. Contractor shall also be protected against claims for injury, disease, or death of employees which, for any reason, may not fall within the provisions of a workers' compensation law. This policy shall include an "all states" or "other states" endorsement. SC -1 The liability limits shall be not less than: Workers' compensation Statutory Employers' liability $2,500,000 - SC -5.4.4 Owner's Protective Liability Insurance. This insurance shall be issued in the name of OWNER and shall protect and defend OWNER against claims arising as a result of the operations of CONTRACTOR or CONTRACTOR'S Subcontractors. (No substitutions for this policy) The liability limits shall be not less than: Bodily injury and property damage $2,500,000 combined single limit for each occurrence* $ 375,000 each person* SC -5.4.5 Commercial General Liability Insurance. This insurance shall be occurrence type written in comprehensive form and shall protect CONTRACTOR, and OWNER and ENGINEER as additional insureds, against claims arising from injuries, sickness, disease, or death of any person, or damage to property arising out of performance of the Work. The policy shall also include personal injury liability coverage, contractual liability coverage, completed operations and products liability coverage, and coverage for blasting, explosion, collapse of buildings, and damage to underground property. The liability limits shall not be less than: Bodily injury and property damage $2,500,000 combined single limit for each occurrence* $375,000 each person` SC -5.4.6 Comprehensive Automobile Liability Insurance. This insurance shall be occurrence type written in comprehensive form and shall protect CONTRACTOR, and OWNER and ENGINEER as additional insureds, against all claims for injuries to members of the public and damage to property of others arising from the use of motor vehicles, either on or off the Project site whether they are owned, nonowned, or hired. The liability limits shall be not less than: Bodily injury and property damage $2,500,000 combined single limit for each occurrence* $375,000 each person* `Plus increases as provided by Section 537.610 RSMo. SC -2 SC -5.4.7 Persons and entities to be shown as insured include CONTRACTOR and: OWNER: CITY OF CAPE GIRARDEAU ARCHITECT: PHILLIP B. SMITH ARCHITECT LLC SC -5.5 Delete paragraph 5.5 of the General Conditions in its entirety. SC -5.6 Delete paragraph 5.6 of the General Conditions in its entirety. SC -5.7 Delete paragraph 5.7 of the General Conditions in its entirety. SC -5.8 Delete paragraph 5.8 of the General Conditions in its entirety. SC -5.10 Delete paragraph 5.10 of the General Conditions in its entirety. SC -5.11 Delete paragraph 5.11 of the General Conditions in its entirety. SC -5.12 Delete paragraph 5.12 of the General Conditions in its entirety. SC -5.13 Delete paragraph 5.13 of the General Conditions in its entirety. SC -5.14 Delete paragraph 5.14 of the General Conditions in its entirety. SC -5.15 Delete paragraph 5.15 of the General Conditions in its entirety. SC -6.3 Add additional sentences to the end of paragraph 6.3 of the General Conditions as follows: "Night work may be undertaken as a regular procedure with the permission of OWNER; such permission shall be requested in writing through OWNERS ENGINEER and may be revoked by OWNER at any time if CONTRACTOR fails to maintain adequate equipment and supervision for proper prosecution and control of the work at night. Night work shall be that work occurring between sunset and sunrise." SC -6.11 Delete paragraph 6.11 of the General Conditions in its entirety and insert the following in its place: " All work performed for CONTRACTOR by a Subcontractor or Supplier will be pursuant to an appropriate agreement between CONTRACTOR and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of OWNER and ENGINEER." SC -7.5 Add paragraph should CONTRACTOR cause damage to the work or property of any separate contractor at the site, or should any claim arising out of CONTRACTOR'S performance of the Work at the site be made by any separate contractor against CONTRACTOR, OWNER, ENGINEER, ENGINEER'S Consultants, the Construction Coordinator or any other person, CONTRACTOR shall promptly attempt to settle with such other contractor by agreement, or to otherwise resolve the dispute by arbitration or at law. CONTRACTOR shall, to the fullest extent permitted by Laws and Regulations, indemnify and hold OWNER, ENGINEER, ENGINEER'S Consultants and the Construction SC -3 Coordinator harmless from and against all claims, damages, losses and expenses (including, but not limited to, fees of engineers, architects, attorneys and other professionals and court and arbitration costs) arising directly, indirectly or consequentially out of any action, legal or equitable, brought by any separate contractor against OWNER, ENGINEER, ENGINEER'S Consultants or the Construction Coordinator to the extent based on a claim arising out of CONTRACTOR'S performance of the Work. Should a separate contractor cause damage to the Work or a property of CONTRACTOR or should the performance of Work by any separate contractor at the site give rise to any other claim, CONTRACTOR shall not institute any action, legal or equitable, against OWNER, ENGINEER, ENGINEER'S Consultants or the Construction Coordinator or permit any action against any of them to be maintained and continued in its name or for its benefit in any court or before any arbiter which seeks to impose liability on or to recover damages from OWNER, ENGINEER, ENGINEER'S Consultants orthe Construction Coordinatoron account of any such damage or claim. If CONTRACTOR is delayed at any time in performing or furnishing Work by any act or neglect of a separate contractor and OWNER and CONTRACTOR are unable to agree as to the extent of any adjustment in Contract Times attributable thereto, CONTRACTOR may make a claim for an extension of times in accordance with Article 12. An extension of the Contract Times shall be CONTRACTOR'S exclusive remedy with respect to OWNER, ENGINEER, ENGINEER'S Consultants and Construction Coordinator for any delay, disruption, interference or hindrance caused by any separate contractor. This paragraph does not prevent recovery from OWNER, ENGINEER, ENGINEER'S Consultant or Construction Coordinator for activities that are their respective responsibilities. SC -8.5 Delete paragraph 8.5 of the General Conditions in its entirety. SC -9.10 Delete paragraph 9.10 of the General Conditions in its entirety and insert the following in its place: "ENGINEER will have authority to determine the actual quantities and classifications of items of Unit Price Work performed by CONTRACTOR, and the written decision of ENGINEER on such matters will be final, binding on OWNER and CONTRACTOR and not subject to appeal. SC -12.3 The following shall be added: SC -12.3.1 Time extensions for abnormal weather conditions. The weather experienced at the project site during the contract period must be found to be unusually severe or abnormal than adverse weather normally anticipated for any given month. The abnormal weather must actually cause a delay to the completion of the project. The delay must be beyond the control of the Contractor. The following schedule of monthly anticipated adverse weather is based on National Oceanic and Atmospheric Administration data and will constitute the base line for weather time evaluations. Mom, L JAN FEB MAR APR MAY JUNE JULY AUG SEPT OCT NOV DEC CALENDAR DAY 9 9 11 11 10 9 9 9 8 7 9 10 CONTRACTS WORKING DAY 4 5 5 6 7 8 9 9 6 7 7 7 SC -14.2 Modify paragraph 14.2 of the General Conditions by inserting the following sentence before the last sentence: " Payments for such materials and equipment shall be based only upon the actual cost of the materials and equipment to CONTRACTOR and shall not include any overhead or profit to CONTRACTOR." SC -14.7.4 Modify paragraph 14.7.4 of the General Conditions by changing the period after the word inclusive to a comma and adding the phrase "or liability for liquidated damages has been incurred by Contractor". SC -16 Delete Article 16 of the General Conditions in its entirety. SC -5 SUPPLEMENTARY CONDITIONS PROJECT: A. C. Brase Arena Renovations 410 Kiwanis Drive Cape Girardeau, Missouri SCOPE These Supplementary Conditions shall apply to all Divisions of the Specifications. If there is any conflict in the "Instructions to Bidders" and "General Conditions" with these Articles, the Special Conditions shall govern. DIVISION OF SPECIFICATIONS The division of specifications into section is done for convenience of reference and is not intended to control the Contractor in dividing work among Subcontractors or to limit the scope of work performed by any trade under any given section. LIQUIDATED DAMAGES $500 per day. See paragraph 3.2 in the agreement between owner and contractor. RETAINAGE Refer to paragraph 5.1.1 in the agreement between Owner and Contractor. SALES TAX The Owner is exempt from sales taxes. PERFORMANCE AND PAYMENT BONDS See section 5.1 of the General Conditions. BUILDER'S RISK INSURANCE The contractor shall purchase and maintain property insurance upon the work at the site in the amount of the full replacements cost thereof. This insurance shall: Include the interest of owner, contactor, subcontractors, engineer, engineer's consultants, each of whom is deemed to have an insurable interest and shall be listed as an insured or additional insured; Be written on a builder's risk "all-risk" or open peril or special causes of loss policy form that shall at least include insurance for physical loss or damage to the work, temporary buildings, falsework and work in transit and shall insure against at least the following perils, fire, lightning, extended coverage, theft vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of laws and regulations and water damage; Include expenses incurred in the repair or replacement of any insured property; Cover materials and equipment stored at the site or at another location that was agreed to in writing by owner prior to being incorporated in the work, provided that such materials and equipment have been included in an application for payment recommended by the architect; and be maintained in effect until final payment is made unless otherwise agreed to in writing by owner, contractor, and architect with thirty days written notice to each other additional insured to whom a certificate of insurance has been issued. PREVAILING WAGE All wages paid for work under this contract shall comply with the requirements of the prevailing wage law of the State of Missouri. See attached Annual Wage Order No. 15 for Cape Girardeau County CONSTRUCTION SCHEDULE Refer to paragraph "5" of the Bid Form. PRECONSTRUCTION CONFERENCE After award of the contract, a preconstruction conference will be scheduled by the Architect to review the requirements of the project. The Owner, Architect, Contractor and its superintendent and major subcontractors shall be represented at the conference by persons familiar with and authorized to conclude matters relating to the work - SC -6 SUPPLEMENTARY CONDITIONS TEMPORARY UTILITIES The contractor may connect to the Owner's utilities for temporary water and electrical power for construction purposes. The Contractor shall conserve utilities during construction. PROTECTION All pollution including but not limited to dust, noise, odors, smoke, and vibrations from work operations shall be held to a minimum. The contractor shall provide additional devices and materials as required to contain dust within the work are and protect employees and the public during construction. Prevent erosion of soil adjacent property owners. PERMITS All permits necessary for the complete construction shall be obtained by the Contractor from the City of Cape Girardeau. The City of Cape Girardeau will waive the cost of the permit. MISCELLANEOUS • Contractor shall keep construction area clean at all times. • Contractor shall repair and seed and straw all disturbed areas. MONTHLY INVOICES AND FINAL PAYMENT • Invoices must be to the Architect by the 15`h of the month. The city requires invoices to be submitted by the 20th to be paid by the 10`h of the following month. • The contractor will be required to submit lien wavers on a monthly basis. • The contractor will be required to submit the "Contractor's Warranty", "Affidavit Compliance with the Prevailing Wage Law" and "Contractor's Affidavit Regarding Settlement of Claims". • The contractor will be required to submit consent of surety for final payment. OWNER OCCUPANCY The owner will occupy the site and existing building during the entire construction period. The contractor shall cooperate with the Owner during construction operations to minimize conflicts and to facilitate Owner usage. Perform the work so as to minimize interference with the Owner's operation. Take all precautions necessary to protect the building and its occupants during the construction period. Maintain the existing building in a watertight condition throughout the construction period. Repair damage caused by construction operations. The Contractor shall coordinate with the Owner for locations of temporary water and electrical connections. The contractor shall abide by the following: • No smoking or tobacco products in the building. • Contractor shall not use Owner's toilets. • The construction area is expected to be cleaned on a daily basis. Trash, debris, dirt on the pavement and walks is to be cleaned on a daily basis. • Coordinate with owner 48 hours in advance when the power, gas, water and sewer are to be turned off or unavailable. END OF SPECIAL CONDITIONS SC -7 Phillip B. Smith ARC HITEC T LLC 332 South Silver Springs Road s Cape Girardeau, Missouri 63703 ■ 573.651.9001 ® f ax 573.651.9073 Bid Date: March 17, 2009 A. C. Brase Arena Arch File No. 0844 10:00 am Building and HVAC Renovations 410 Kiwanis Drive Cape Girardeau, Missouri Zoellner Construction 875 PCR 500 Perryville, MO 63755 573 - 547-8030 573 - 547-8034fx Base Bid 819,740.00 131,100.00 Alt No. 1 Bldg Addn 41,900.00 Alt No. 2 Canopies 6,350.00 Alt No. 3 Sign 24,400.00 Alt No. 4 Stage AC 16,900.00 Alt No. 5 Temp Ctrls 205,600.00 Alt No. 6 Generator 25,450.00 Alt No. 7 Stage Pwr 8,500.00 Alt No. 8 LP3 — SW 6,000.00 Alt No. 9 LP5 — SE 10,200.00 Alt No. 10 LP6 — NE Total 1,296,140.00 A. C. Brase Arena Renovations Department of Parks and Recreation 410 Kiwanis Drive Cape Girardeau, Missouri Architect File No. 08-44 Index of Drawings COVER SHEET CIVIL EXISTING SITE CONDITIONS C1.0 ARCHITECTURAL DEMOLITION ROOF PLAN D1.1 EXISTING FLOOR PLAN A1.1 NEW ROOF PLAN A1.2 EXTERIOR ELEVATIONS & ALTERNATE NO. 3 A2.1 EXTERIOR ELEVATIONS A2.2 BUILDING SECTIONS A2.3 DETAILS A3.1 ALTERNATE NO. 1: BLDG. ADDITION - PLAN A4.1 ALTERNATE NO. 1: BLDG. ADDITION - FOUNDATION & FRAMING PLAN A4.2 ALTERNATE NO. 1: BLDG. ADDITION - ELEVATIONS A4.3 ALTERNATE NO. 1: BLDG. ADDITION - SPECIFICATIONS & STRUCTURAL DETAILS A4.4 ALTERNATE NO. 1: BLDG. ADDITION -TYPICAL STRUCTURAL DETAILS A4.5 ALTERNATE NO. 2: CANOPY AND DETAILS A5.1 PICTURES: 1 THRU 12 A6.1 PICTURES: 13 THRU 24 A6.2 PICTURES: 25 THRU 36 A6.3 PICTURES: 37 THRU 40 A6.4 EXTERIOR COLOR SCHEME A7.1 MECHANICAL MECHANICAL FLOOR PLAN HVAC SYSTEM M1.1 MECHANICAL ROOF PLAN HVAC SYSTEM M1.2 MECHANICAL SECOND FLOOR & ADD ALT 1 HVAC SYSTEM M1.3 MECHANICAL DETAILS & SCHEDULES M1.4 PLUMBING PLUMBING FLOOR PLAN P1.1 ELECTRICAL ELECTRICAL FLOOR PLAN E1.1 ELECTRICAL ROOF PLAN E1.2 ELECTRICAL TUNNEL PLAN E1.3 ELECTRICAL SECOND FLOOR & ALL ALT. 1 E1.4 ELECTRICAL SITE LIGHTING E1.5 ELECTRICAL RISERS E1.6 ELECTRICAL POWER SUPPLY DETAILS E1.7 ELECTRICAL DEMO PHOTOS & PANEL SCHEDULES E1.8 ELECTRICAL DEMO PHOTOS & PANEL SCHEDULES E1.9 Page 1 of 1 CITY OF CAPE GIRARDEAU Department of Parks and Recreation A. C. Brase Arena Renovations 410 Kiwanis Drive CAPE GIRARDEAU, MISSOURI BID FORM (EJCDC 1910-18) (1990) PROJECT IDENTIFICATION: The improvement consists of building additions, roof replacement, exterior wall improvements, HVAC replacement, electrical upgrades and emergency generator and all other appurtenances as specified in the bid documents for the project. The building is located at 410 Kiwanis Drive, Cape Girardeau, Missouri. THIS BID IS SUBMITTED TO: DANIEL MUSER, DIRECTOR OF PARKS AND RECREATION PARKS AND RECREATION DEPARTMENT 410 KIWANIS DRIVE CAPE GIRARDEAU, MO 63703 1. The undersigned BIDDER proposes and agrees, if the Bid is accepted, to enter into an agreement with OWNER in the form included in the Contract Documents to perform and furnish all Work as specified or indicated in the Contract Documents for the Bid Price and within the Bid Times indicated in this Bid and in accordance with the other terms and conditions of the Contract Documents. 2. BIDDER accepts all of the terms and conditions of the Advertisement or Invitation to Bid and Instructions to Bidders, including without limitation those dealing with the disposition of Bid security. This Bid will remain subject to acceptance for thirty-five days after the day of Bid opening. BIDDER will sign and deliver the required number of counterparts of the Agreement with the Bonds and other documents required by the Bidding Requirements within fifteen days after the date of OWNER'S notice of Award. 3. In submitting this Bid, BIDDER represents, as more fully set forth in the Agreement, that: (a) BIDDER has examined and carefully studied the Bidding Documents and the following BF -1 Addenda, receipt of all which is hereby acknowledged: (List Addenda by Addendum Number and Date) leo f21i1i2C0 17-, Zoocl (b) BIDDER has visited the site and become familiar with and is satisfied as to the general, local and site conditions that may affect cost, progress, performance and furnishing of the Work; (c) BIDDER is familiar with and is satisfied as to all federal, state and local Laws and Regulations that may affect cost, progress, performance and furnishing of the Work. (d) BIDDER has carefully studied all reports of explorations and tests of subsurface conditions at or contiguous to the site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the site (except Underground Facilities) which have been identified in the Supplementary Conditions as provided in paragraph 4.2.1 of the General Conditions. BIDDER accepts the determination set forth in paragraph SC -4.2 of the Supplementary Conditions of the extent of the "technical data" contained in such reports and drawings upon which BIDDER is entitled to rely as provided in paragraph 4.2 of the General Conditions. BIDDER acknowledges that such reports and drawings are not Contract Documents and may not be complete for BIDDER'S purposes. BIDDER acknowledges that OWNER and Engineer do not assume responsibility for accuracy or completeness of information and data shown or indicated in the Bidding Documents with respect to Underground Facilities at or contiguous to the site. BIDDER has obtained and carefully studied (or assumes responsibility for having done so) all such additional or supplementary examinations, investigations, explorations, tests, studies and data concerning conditions (surface, subsurface and Underground Facilities) at or contiguous to the site or otherwise which may affect cost progress, performance or furnishing of the Work or which relate to any aspect of the means, methods, techniques, sequences and procedures of construction to be employed by BIDDER and safety precautions and programs incident thereto. BIDDER does not consider that any additional examinations, investigations, explorations, tests, studies or data are necessary for the determination of this Bid for performance and furnishing of the Work in accordance with the times, price and other terms and conditions of the Contract Documents. (e) BIDDER is aware of the .general nature of Work to be performed by Owner and others at the site that relates to Work for which this Bid is submitted as indicated in the Contract Documents. (f) BIDDER has correlated the information known to BIDDER, information and observations obtained from visits to the site, reports and drawings identified in the Contract Documents and all additional examinations, investigations, explorations, tests, studies and data with the Contract Documents. ,k BF -2 4= (g) BIDDER has given Engineer written notice of all conflicts, errors, ambiguities or discrepancies that BIDDER has discovered in the Contract Documents and the written resolution thereof by ENGINEER is acceptable to BIDDER, and the Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performing and furnishing the Work for which this Bid is submitted. (h) This Bid is genuine and not made in the interest of or on behalf of any undisclosed person, firm or corporation and is not submitted in conformity with any agreement or rules of any group association, organization or corporation; BIDDER has not directly or indirectly induced or solicited any other Bidder to submit a false or sham Bid; BIDDER has not solicited or induced any person, firm or corporation to refrain from bidding; and BIDDER has not sought by collusion to obtain for itself any advantage over any other Bidder or over OWNER. 4. BIDDER will complete the Work in accordance with the Contract Documents for the following price: Base Bid: General Construction: Roofing: Exterior Wall Surface Renovation: HVAC: Electrical- Total Base Bid: $ 50 040 ,to $ l 0 , c)o ID ,mac $ r3f� fa o en Figure (Base Bid): 616tj j I-GfND2C-6 til 'C1 CeiJ 7 -4 -to c(5A A) -D S �-6(1)W D FQf 2 -TU A -Rn N0/ lo ars Alternate Number One (Building Additions): General Construction: HVAC: $ 5, 6 ccs,- 6�0 Plumbing: $ (2� 6 y 0, Electrical: $ 7, Doe Total Alternate Number One Bid: $ j-3 j , I !D C) ,� v Written Figure (Alternate No. One): QA)6 "ND250 TH-C � W 1) Cie- OAJ&5- ( q NAZ D fiW d /OLS - ars Alternate Number Two (Three canopies at West elevation Lump sum bid for alternate number two: $ �� D� �a 121 BF -3 b Nc i 4o tis ?-Aw N/loc--, Alternate Number Three (Sign at West elevation): Lump sum bid for alternate number three: $ �� 350 `0 Fiau Three): S i X_ -t 40 USA-<L'W Alternate Number Four (HVAC -5, Stage Unit):` I Lump sum bid for alternate number Four: $ --a`� 40 � Written Figure (Alternate No- Four): rwC-fiT-I (Fvutz1 tf-0U S4`u0 FOu2 (fiVOOJ5GD Aft/D A161 i Dv - uollars Alternate Number Five (Web -Based Temperature Control System): Lump sum bid for alternate number Five: $ 162, gooloo Written Figure Alternate No. Five): S i �aC60 106)v-!5Al'vo Ntv1je A ivo I1r, / W _ -Dollars Alternate Number Six (Generator with enclosure and concrete pad": Lump sum bid for alternate number Six: $ Written Figure Alternate No. Six): GU0 t4UAIOtZ �0 61K TW04L.1k12,0 S:[k 441A 1047 PO A -A/D ffd / 03 - _ _ Uo I la r,, Alternate Number Seven (600A Stage Performance power supply): Lump sum bid for alternate number Seven: $ S� yea, oG> Written Figure Alternate No. Seven):-TUf F106 1400 �,441_6 -0zi2 ( .11 nln ri�-0 F�-/ r-,� r -k 0 A)0 /(W ollars Alternate Number Eight (Southwest power panel LP3 and related work): Lump sum bid for alternate number Eight: $ 50 0.e Alternate Number Nine (Southeast power panel LP5 and related work): Lump sum bid for alternate number Nine: $ (4, a00, 0, Written Figure (Alternate No Nine): SIC _r4-0d4r `3 04/0 oliars Alternate Number Ten (Northeast power panel LP6 and related work): Lump sum bid for alternate number Ten: $ to Z ° C) Written Figure Alternate No. Ten): N -r400- -&],O "frA' n10 r(tr Dollars • NE (Total bid amount is to be shown in both words and figures. qIn case of discrepancy, the amount shown in words will govern. ����J�`1�� 5. BIDDER agrees that the Work will be substantially complete by August 9, 2009. The Work will be completed and ready for final payment in accordance with paragraph 14.13 of the General Conditions by August 28, 2009. BIDDER accepts the provisions of the Agreement as to liquidated damages in the event of failure to complete the Work within the times specified in the Agreement. 6. The following documents are attached to and made a condition of this Bid: (a) Required Bid Security in the form of bid bond or cashiers check. (b) Required BIDDER'S Qualification Statement with supporting data. (c) Any Addenda issued. 7. Communications concerning this Bid shall be addressed to: Name LCL-c-AlEk CNST-RUC-TlOti w., .=NC• Address F'15 ?C9, 5-60 , P;5P-F-YVjc-LE AD (o3715 (a) Performance and Payment Bonding Company Name Address P•0. -bog 5-077 c JDA f AL.Ls -, SP 7117"5077 Agent\Power of Attorney Name (if used) W61-sCH riATN&Ss LqT-e Address 30 8 14. Z I ST STREP urs 3103 8. Terms used in the Bid which are defined in the General conditions or Instructions will have the meanings indicated in the General Conditions or Instructions. SUBMITTED on MA -R -&O )-3 , 20A. 114 1550Q ►Zi Contractor License No. 0 G 3 -7 31 BF -5 IF BIDDER is: An Individual By doing business as Business address: Phone No.: A Partnership By Business address: Phone No.: (Ndividual's Name) (Firm lame) (Genera%Partner) MM (SEAL) (SEAL) A Corporation n By Z(�iCf_C,N6k_ �DNS"-TeT(D� D, ��1(� . ( SEAL) (Corporation Name) M ISS O U ILI State of Incorporation) By c (U -s1/ >c!Z- (SEAL) (Name of Person Authorized to Sign (Title) (Corporate Sea Atte Business address: (Secretary) F-75 5�O o iE-A 2w V I t- C C Phone No.: S'13 - 5 �{ -7 - g D 3 O Date of Qualification to do business is Nov • 3 0 (o3 -77S J�tt�tu (SEAL) By (Name) (Address) (SEAL) By \ \ (Name) (Address) Phone Number and Addresp for receipt of official communications: (Each joint venturer must sign. T e manner of signing for each individual, partnership and corporation that is a party to the joint venture should be in the manner indicated above.) BF -7 BREAKDOWN OF WORK FORCE (Required): BIDDER hereby states that he will perform the following items of work directly without employment of subcontractors: L 31-(�E-G C—_/Z r&7_( 0111 It is anticipated that the following subcontractors will be employed for work on this project: SUBCONTRACTORS: D1 Roofing: 22I (. GI �` �' �f1 � N C' (Attach roof subcontractor's qualification sheet) Exterior Wall Surface Painting and Repair: Exterior Insulation and Finish System: Masonry: Metal Studs: Gypsum Board and Finish: Interior Painting Concrete: Steel Fabrication and Erection: HVAC: Plumbing: Electrical: : J S 41/4'Son! r - �a-u Q_ L P AO Ski /U �v Et-c.n� CMZ rO 2G LlfiN&�-_ V r&b 03/17/2009 08:18 5735478034 ZOELLNER CONST CO 03/17/2009 08:58 FAX 5733340089 A. C. Brase! Arena Renovations 410 KmftS Drive, cape 01mr6mu, Missouri Architect File No, 08" ROOFING CONTRACTOR QUALIFICATION INFORMATION Contractor Narne; Contractor Actress: P.0 BOX 1544 Ctty, State, Z p Code: a Girardeau MO 63702 Phone Number Fax Number: 573.334.0089 Contact Person: Charles ftw Propow m2terial: TPO Proposed meWals manufacWrer- Firestone How long hwi the Inetaller been an approved, authorized or lioensed by the proposed roofing material manufacturer to install the project: 20+ Years F�ovida a %T tterl letter hvm rhe mantifoaurgr sMting that the roofing oantractcrlsubmn"cfix !s an approved and &*piked installer_ Provide four (4) reterencee of projects of similar 8120 and comploxlty that tt16 rvoflng conVactor/suboantracor h9s successfu8y completed in the past four (4) years. PmPerty Owner name: SEM state University Contact person; Lisa Howe p #: 573.651 .2723 PrO00 addreaw One Ufti4 *� Place Girardeau M7 63701 When was the project Completed Typo of roofing material used: Approximate square footage: InstzdieWn time period: RxRrq cost. PAGE 02/03 la003/004 •03/17/2009 08:18 5735478034 ZOELLNER CONST CO PAGE 03/03 03/17/2009 08:59 FAX 5733340089 R004/004 A. C. Brase Arena Renovations 410 Xhvanly dr ve, Cape elmrdesu, Iw mswA AmNtedt File ND.: 0844 07wsroads Strip Met: — Cape Gi.zaxdeau, MJ 2. Prolo" owner name: McLane IrmestUmts — -- Contact person: Chris Viler Phone*, 573.335.0002 Project address: 125 S. Broadview, Ste 9 Cate Girardeau MID 63701 "M was the project compk*ed: Type of rooting material used: Approximate eRuare footage: Insiallation tune period; Roofing cast: 3. Prc perty Owner name: Memorial HOspitai of CarborAale Contact person; Dan Evam M Phone#: 518.529.0451 Prcjeat address: 4k5_,W UacksM -- - - 94imdaIe IL 62901 When was the project completed: Type of rooting material used: Approximate square footage: _ ---- Inatalation time period: Rcofing cost; -- 4. Property Owner name: SEMD Hospital—Weat gains MM Crrntact parson: Kent xiefrier Pune#: 573.334.0707 Project address: Cape GirazdeaU MQ A hen was the project completed., Type of roofing material used: Approximeta square footage: Ir atallation time period; Foofing cost: THE AMERICAN INSTITUTE OF ARCHITECTS to AIA Document A310 Bid Bond KNOW ALL MEN BY THESE PRESENTS, that we Zoellner Construction Co., Inc., 875 PCR500, Perryville, MO 63775 as Principal, hereinafter called the Principal, and Western Surety Company P.O. Box 5077, Sioux Falls, South Dakota, 57117-5077, (605) 336-0850 a corporation duly organized under the laws of the State of South Dakota as Surety, hereinafter called the Surety, are held and firmly bound unto City of Cape Girardeau 401 Independence Street Cape Giradeau MO 63703 as Obligee, hereinafter called the Obligee, in the sum of Five Percent of the Total Amount Bid Dollars( 5%) for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for (Here insert full name, address and description of project) A. C. Brase Arena Renovations NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 17th day of March, 2009 A;�� (Witness) ZoelJner Constructiob Co., Inc. Com (Principal) (Seal) (Surety) (Seal) Barbara J. LemnY (Title) Attorney -in -Fact AIA DOCUMENT A310 - BID BOND - AIA ® - FEBRUARY 1970 ED - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE., N.W., WASHINGTON, D. C. 20006 ' Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY_ -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint Dennis D Flatness, Dennis W Lutz, Barbara M Johnson, Taffra S Holman, Susan M Stefanski, Barbara J Lemm, Individually of Saint Louis, MO, its true and lawful Attomey(s)-in-Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Senior Vice President and its corporate seal to be hereto affixed on this 18th day of October, 2006. suaery, WESTERN SURETY COMPANY Paul . Bruflat, Senior Vice President State of South Dakota ss County of Minnehaha On this 18th day of October, 2006, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Senior Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires + S r D. KRELL i November 30, 2012rNOTARY PUBLIC 3 A� i r SEAL SOUTH DAKO�TA.r r r +tip-,SSSss5s55tiyyv555',stiss + CERTIFICATE D. Krell, No ary Public 1, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this _ 17th day of March 2009 WESTERN SURETY COMPANY �"Qio0.?ORq�'s o' H DpK� Form F4280-09-06 L. Nelson, Assistant Secretary Authorizing By -Law ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. Philh-n B. Smith ARC HITE C TLLc 332 South Silver Springs Road s Cape Girardeau, Missouri 63703 ■ 573.651.9001 ir fax 573.651.9073 March 12, 2009 Addendum No. (1) One A. C. Brase Arena Renovation City of Cape Girardeau, Dept of Parks and Recreation 410 Kiwanis Drive Cape Girardeau, Missouri Arch. File No. 0844 This document is an amendment of the original specifications and/or drawings and shall be part of and included in the contract. Wherein this addendum conflicts with the original specifications and drawings, this addendum shall govern: Item # 1: Specifications: Notice To Bid: Contractors are to deliver bids to the A. C. Brase Arena Building receptionist at the West entrance, March 17, 2009 at 10:00 am. Bids will be publicly opened at the inside bleacher seating area. Item # 2: Specifications: Bid Form, page BF -5, paragraph 5: Change August 9 to August 29. Item # 3: Specifications: Supplementary Conditions - add the following: " Pursuant to 285.530 RSMo, the bidder must affirm its enrollment and participation in a federal work authorization program with respect to the employees proposed to work in connection with the services requested herein by 1) submitting a completed, notarized copy ofAFFIDAVIT OF WORK A UTHORIZA TION and 2) providing documentation affirming the bidder's enrollment and participation in a federal work authorization program with respect to the employees proposed to work in connection with the services requested herein." See also the attached "Affidavit of Work Authorization" form. Item # 4: Specifications: Supplementary Conditions - Construction Schedule: Bid Date: March 17, 2009 City Council Meeting: April 6, 2009 (to approve bid) Contract with Contractor: April 7 - 9, 2009 Start Construction: April 13, 2009 Power switch -over: July 27 - August 6, 2009 Must have power to building: August 7, 8, 14 and 15, 2009. Substantial completion: August 21, 2009 100% completion (punch list complete): August 28, 2009 Item # 5: Specifications: Supplementary Conditions - Owner Occupancy: The building will be occupied by the Owner and used by the public for various pre - scheduled events. The Contractor shall coordinate all interior and exterior work with the Owner's schedule of events. Lifts, scaffolding, and etc. on the interior may have to be removed for certain scheduled events during the construction period. These items will be coordinated in advance during the construction meetings. Item # 6: Specifications: Supplementary Conditions - Miscellaneous: The contractor can occupy the part of the parking area to the North for staging and storage of materials. Item # 7: Specification Section 07 26 00 - Underslab Vapor Barrier: 2.1 Add Stego Industries LLC, StegoWrap, 10 mil, Class A Vapor Retarder as an approved manufacturer subject to compliance with specifications. Page 1 of 2 A. C. Brase Arena Renovation Addendum No. 1 03-12-2009 Item #8: Specification Section 07 54 23 — TPO Roofing: 2.1.A.1 Add "Versico' as an approved manufacturer subject to compliance with the specifications. Item # 9: Sheet A 1.1: Door numbers: Door labeled 105 at southeast area should be Door 103. Door labeled 105 at southwest area should be Door 104. Door labeled 105 at northeast area is correct. Item # 10: Sheet A 1.1: Construction note "8": See attached Detail 24/ A 3.1. Item # 11: Sheet Al. 1: Add construction notes: [9] Patch concrete roof deck where HVAC return air duct is removed at each unit at West and East, typical of 6 locations at flat concrete roof. See attached Detail 25/ A 3.1. [10] Infill opening through arched wood roof deck where HVAC supply duct is removed, typical of 6 locations. Infill with 2 x 8 lumber — remove section of boards as required to allow new boards to bear on wood beam at each end. Attach to wood beam below with 16 d common nails. [11] Once the six roof HVAC units are removed at the arched roof, remove the supply and return grilles, install new I.ay-in ceiling panels at interior grille locations. Match existing 2 x 4 ceiling tiles. Field verify quantity. Repair ceiling grid as required at supply grilles. Item # 12: Sheet A1.2: Provide all tapered insulation with % inch slope per foot. Roof Type 1: (Flat concrete area), the new insulation is to be fully adhered to the concrete slab. Roof Type 2: (Arched roof), the new insulation is to be mechanically fastened to the wood substrate. Item # 13: Provide a 22 gauge, pre -finished metal window sill flashing to cover the EIFS at the existing projection booth window (south elevation). Extend flashing under window sill and down EIFS approximately 3" with formed drip edge at bottom. Caulk flashing at window and EIFS. Item # 14: Provide 1'/2 x 1'/ wood framing behind wall mounted AC units in lobby. Cover framing with %" birch plywood at all exposed four sides and paint white. Verify size of cover to match size of AC unit. (2 required.) Item # 15: Provide three windows centered in the south wall of Office 104 as part of Add Alternate No. 1: Window Specification: Pella Window, Designer Series, 2141, Frame Size: V-9" w x 3'-11" h, Endura Clad, Three operable windows mulled together. Stain interior wood to match existing window. Glass: Double pane with Slimshade Blinds. Insect screen, no grilles and standard hardware. Mount at same elevation as existing window. Provide masonry lintel above window opening. See architectural attachments. See attached Mechanical, Plumbing and Electrical items from Strickland Engineering End of Addendum No. (1) One. Page 2of2 Comes now my oath, affirm EXHIBIT AFFIDAVIT OF WORK AUTHORIZATION Name as Office held first being duly sworn, on is enrolled and will continue to Company Name participate in a federal work authorization program in respect to employees that will work in connection with the contracted services related to Project Name for the duration of the contract, if awarded in accordance with RSMo Chapter 285.530 (2). I also affirm that does not and will not knowingly Company Name employ a person who is an unauthorized alien in connection with the contracted services related to Project name for the duration of the contract, if awarded. In Affirmation thereof, the facts stated above are true and correct (The undersigned understands that false statements made in this filing are subject to the penalties provided under Section 575.040, RSMo). Signature (person with authority) Subscribed and sworn to before me this of commissioned as a notary public within the County of of Printed Name Date and my commission expires on Signature of Notary Date 20 I am State CHIMNEY OPENING. COPE ON LEG AND BEAR ON CONCRETE WALL. 314" THICK CDX PLYWOOD SHEATHING- ANCHOR TO CONCRETE WALL WITH 114" CONCRETE ANCHOR AT 16" O.C. TAPERED INSULATION (SLOPE TO SOUTH) U41TE TPO ROOF MEMBRANE. ANCHOR 2 x 4 WITH 114" CONCRETE ANCHOR AT 16" O.C. PRESSURE TREATED 2 x 4 AT PERIMETER OF CHIMNEY OPENING. PREFIN16HED METAL COPING WITH CONTINUOUS CLEAT. EXISTING CONCRETE CHIMNEY WALL. 24 CHIMNEY EDGE DETAIL A3.1 SCALE: 11% , = V - m„ WK PFlLF B %XM ARCH ECT LLC 2009 MO. UC. NO. A -M T TRLE: 34DW 0 1 PROJECT l NO. 1 08-44 DATE: a P2.09 CAD DWQ F=LE: 08^44_.x -FW dwa �I I{CFIECKED DRAWN BY& DW BY: P83 A.C. Brase Arena Phillip B. Smith Building Renovation 1ARCH I TE C T LLc 410 Kiwanis Drive 332 South Silver Springs Road Cape Girardeau, Missouri 63703 Cape Girardeau, Missouri Phone: 5 7 3.6 5 1.9 0 0 1 Fax: 5 7 3.6 5 1-9073 25 ROOF SLAB DETAIL A3.1 SCALE: it%" = 1' - 0" PoOW PK1F B. BMTTH ARCHITECT LLC 2009 MO. UC, NO. A- W T MTLB Ncw t1 PR COE-CT NO.: 08-44 DATE: s. M 09 f# CAD DWG Fib 0�8 44_X-fW.dwg -i [! DRAWN BY- Y: DW Q-ECK® BY: P68 INSTALL NEW 3"t THICK (MATCH EXISTING) CONCRETE SLAB AT OLD RETURN AIR OPENING. INSTALL M 4 BARS AT 12" O.C.- EPDXY INTO EXISTING CONCRETE SLAB V' MINIMUM. EXISTING CONCRETE ROOF STRUCTURE (SLAB AND JOIST) PROVIDE TEMPORARY PLYWOOD FOl-d"I TO POUR CONCRETE. PROVIDE TEMPORARY FORM, BRAGING, AND SUPPORT TO POUR CONCRETE SLAB. A.C. Brase Arena Phillip B. Smith Building Renovation 410 Kiwanis Drive ARCH I T E C T LLc 332 South Silver Springs Road Cape Girardeau, Missouri 63703 Cape Girardeau, Missouri Phone: 5 7 3.6 5 1.9 0 0 1 Fax: 5 7 3.6 5 1.9 0 7 3 I�hilli� � Smi� 332 South Silver Springs Road t R C H I' -- Cape r Cape Girardeau, Missouri 63703 s 573.651.9001 C E C T LLc w fax 573.651.9073 Plan Holder List A. C. Brase Arena — Exterior and HVAC Renovations Cape Girardeau, Missouri Arch File No. 0844 General Contractors: Denali Construction Zoellner Construction Sides Construction P O Box 55 875 PCR 500 P O Box 308 Cape Girardeau, MO 63702 Perryville, MO 63775 Cape Girardeau, MO 63702 fx 651-0027 fx 547-8034 fx: 243-8128 Contrend Inc 840 S Kingshighway Cape Girardeau, MO 63703 fx: 334-4936 Sub -Contractors: Drury Company P O Box 1544 Cape Girardeau, MO 63702 fx: 334-0089 Oberman & Son Inc P O Box 410 Jackson, MO 63755 fx: 243-8083 Powers Electric 861 Co Rd 627 Cape Girardeau, MO 63701 fx: 332-8605 Cotner K Electric 770 Enterprise St Cape Girardeau, MO 63703 fx: 332-1084 Burgess Construction 200 Butterfield Drive Farmington, MO 63640 fx: 573-747-0883 Miller Drywall 1318 Main Street Scott City, MO 63780 fx: 264-2490 Associated Sheet Metal P O Box 237 Jackson, MO 63755 fx: 243-7190 Cotner Electric 2049 Southern Expressway Cape Girardeau, MO 63703 fx: 335-2340 Dreyer Electric Co LLC 16 Saxon Memorial Dr Frohna, MO 63748 fx: 573-824-5226 Crossroads Construction 100 Vineyard Street Park Hills, MO 63601 fx: 573-431-6801 Dutch Enterprises P O Box 438 Jackson, MO 63755 fx: 243-5365 K & K Electric 433 Co Rd 638 Cape Girardeau, MO 63701 fx: 334-2545 MSI Electric P O Box 523 Jackson, MO 63755 fx: 243-4749 Foeste Masonry 347 County Rd 649 Cape Girardeau, MO 63701 fx: 334-0656 - Langford Mechanical & Sheet Metal Midwest Painting Taylor Roofing 1116 Lenco Ave, P O Box 405 P O Box 218 1127 East B Street Jackson, MO 63755 Cape Girardeau, MO 63702 Belleville, IL 62220-4149 fx: 243-8057 fx: 335-0058 fx: 618-277-1066 S & S Interiors Leach Painting Co Loyd Slinkard Painting Co 4587 St Hwy 74 1233 Hanley Industrial Crt 4680B State Hwy 74, P O Box 1687 Cape Girardeau, MO 63701 Brentwood, MO 63144 Cape Girardeau, MO 63702 fx: 332-0833 fx: 314-961-4003 fx: 335-4378 Equipment Supply Distribution Buffington Brothers 468 N Bellevue Blvd 110 N Riverview Memphis, TN 38105 Poplar Bluff, MO 63901 fx: 901-274-0770 fx: 573-785-6768 McGraw Hill Construction Dodge Reed Construction Data as of 3-12-09 2:00 PM STRICKLAND ENGINEERING ADDENDUM ADDENDUM: 1 DATE: March 12, 2009 PROJECT: A.C. Brase Arena Renovations City of Cape Girardeau Parks and Recreation Department Cape Girardeau, Missouri i ITEM SECTION DESCRIPTION HVAC HVAC -1, 2, 3, 4 shall include return air smoke detectors_ Connect to existing fire 1 CLARIFICATION alarm system. Field verify existing system conditions and requirements. Install remote test stations next to controls for each unit. 2 HVAC HVAC -1, 2, 3, 4, 5 do not require final filters. Economizer is to be included with each CLARIFICATION unit. Unit controls shall control economizer operation, not DDC controls stem. 3 HVAC Exterior ductwork jacketing may be per detail or specifications. Both methods are CLARIFICATION acceptable. Roof openings for HVAC -5 shall be 18x18. Do not cut concrete beams. Coordinate 4 HVAC - M1.1 location of ductwork to NOT interfere with existing stage curtains and lighting. Final location shall be approved by Engineer and Architect. 5 HVAC - M1.4 Include detail for supports of round ducting. See sheet 1 of 8. 6 HVAC - M1.2 Modify gas piping as noted - ALL GAS PIPING ON ROOF SHALL BE NEW PIPING,including the piping.over the parapet wall. See sheet 2 of 8. The following manufacturer's are approved EQUALS for Add Alternate #5: 7 HVAC CONTROLS Trane Tracer SC Johnson Controls Carrier CCN 8 ELECTRICAL Pole mounted transformers and cut-out disconnect switches that are being removed from existing electrical services shall be delivered to Owner, 9 ELECTRICAL Furnish and install new high voltage cut-out disconnect switches for new electrical service a uaI to existing cut-outs with required volts a and ampere rating. 10 1 ELECTRICAL Owner shall furnish diesel fuel for new generator. 11 ELECT - E1.1 Furnish and install exit and emergency lights in lobby as shown on sheet 3 of 8. 12 ELECT - E1.3 Sheet 4 of 8 clarifies that new electrical panel shall be LP2 instead of LPI 0. 13 ELECT - E1.5 Modify existing light fixture schedule as shown on sheet 5 of 8. 14 ELECT - E1.8 Furnish and install new exterior 400 watt wall pak light fixtures on North and South walls as shown on Sheet 6 of 8. Modify conduit and wiring as noted. Furnish and install new exterior 100 watt wall pak light fixtures over Northwest 15 ELECT - E1,8 basement entrance and Southwest electrical room entrance as shown on sheet 7 of 8, 16 ELECT - E1,8 I Modify Panel'LPV schedule as shown on sheet 8 of 8. END OF MPE ADDENDUM R T ' N 113 WEST MAIN STREET 80 ® S T j" I C K L A 1� D JACKSON, MISSOURI 63755 E N G I N E E R I N G T AX: 57 -243- 191 FAX: 573-243-2191 CIVIL - MECHANICAL - ELECTRICAL ENGINEERING - LAND SURVEYING DATE: 03/12/09PROJECT: A.C. BRASE ARENA SHEET: 1 OF 8 BUILDING RENOVATION PROJ, NO. 08-115 CAPE GIRARDEAU, MISSOURI DESCRIPTION: M1.1 ADD EXTENSION TO FRAMING TO A HEIGHT DOWN TO 2" ABOVE BOTTOM OF SUSPENDED CEILING, TYP. r NOTE: ON SOUTH WALL INSTALL SEISMIC SWAY BRACING TO MOUNTING FRAMING THAT EXTENDS DOWN TO WITHIN 2" OF BOTTOM OF CEILING. ALSO INSTALL RIGID BRACING FROM DUCTWORK BACK TO WALL. EXISTING EXISTING WOOD ROOF /� FRAMING TYPICAL ROUND DUCTING HANGER NOT TO SCALE EXISTING CEILING UNISTRUT OR _ ANGLE SUPPORT NOTE: INSTALL UNISTRUT OR ANGLE SUPPORT ON BOTTOM OF CEILING AND SECURE TO WOOD STRUCTURE FRAMING 12" OR USING LAG SCREWS. LESS HANG DUCTING W/ SHEETMEfAL STRAP I HANGERS WITH THREADED ROD SUSPENDED FROM FRAMING ABOVE. INSTALL HANGERS SPACED AS REQUIRED DUCTING AS TO SUPPORT DUCTING PER SMACNA SPECIFIED STANDARDS. (TYP) INSTALL CLEARANCE HOLE THRU CEILING TILE. r NOTE: ON SOUTH WALL INSTALL SEISMIC SWAY BRACING TO MOUNTING FRAMING THAT EXTENDS DOWN TO WITHIN 2" OF BOTTOM OF CEILING. ALSO INSTALL RIGID BRACING FROM DUCTWORK BACK TO WALL. EXISTING EXISTING WOOD ROOF /� FRAMING TYPICAL ROUND DUCTING HANGER NOT TO SCALE EXISTING CEILING SIT /� A �T 1 �i 113 WEST MAIN STREET AA� EN 1V (� �g I N j�J E E R �v N G JACKSON, MISSOURI 63755 TEL: 573-243-40802191 FAX: 573-243-2191 L,I v il_ - I"ICL r1H1N1�-/AL - 1--LL(- I HICAL ENGINEERING - LAND SURVEYING DATE: 03/12/09 PROJECT: A.C. BRASE ARENA SHEET: 2 OF 8 BUILDING RENOVATION PROJ. NO. 08-115 CAPE GIRARDEAU, MISSOURI DESCRIPTION: M1.2 IT C 2IA? 1 V NEW 'I UNIT1-1/2" fFRIC R 3 p INPII�I T HEAT NC I NEW Ij Ij 1-1/2" INSTALL TRANSITION TO 30x48 UNIT CONNECTION WITH FLEXIBLE CONNECTION AT UNIT. G NEW 2" CONNECT NEW REUTRN TO EXISTING RETURN AIR SYSTEM THRU EXISTING ROOF CURB CONNECTIONS. REMOVE EXISTING HEATING UNIT. REMOVE G PIPING BACK TO EXISTING 1-1/2" GAS MAI ON ROOF TO CONNECT NEW HVAC UNITS. INSTALL NEW INSULATED WEATHERPROOF CC TO EXISTING CURB AND INSTALL NEW ADAP' CURB FOR NEW HVAC UNITS. CONTRACTOR SHALL SUBMIT SHOP DRAWINGS FOR APPRC ON ADAPTER CURBS. FIELD VERIFY EXISTINC CONDITIONS. EXISTING 2" GAS MAIN PIPING UP FROM GAS METER. SECURE IN PLACE. NOTE: MODIFY EXISTLV�'W.C. G SYSTEM FORRAL GAS. NEW 5 -TON HVAC ROOFTOP UNIT FOR STAGE, HVAC -5 ON ROOFCURB. INSTALL UNDER ASD ALTERNATE#4. FIELD VERIFY LOCATION FOR ROOF SLAB PENETRATIONS DO NOT CUT CONCRETE BEAMS. COORDINATE LOCATIONS WITH ARCHITECT, ROOF PLAN - HVAC SYSTEM SCALE: 1/8" = V-0 113A S T R I C K L A N I C WEST MAIN STREET L .JACKSON, MISSOURI 63755 EN GINE E RING FA 573-243-4080 FAX: 573--243-21912191 CIVIL - MECHANICAL - ELECTRICAL ENGINEERING -- LAND SURVEYING DATE: 03/12/09 PROJECT: A.C. BRASE ARENA SHEET: 3 OF 8 BUILDING RENOVATION PROD. NO. 08-115 CAPE GIRARDEAU, MISSOURI DESCRIPTION: E1.1 UNDER BASE BID WORK (2) EXISTING RECEPTACLES AND SURFACE MOUNTED CONDUIT rSHALL REMAIN AND BE MODIFIED TO BE WIRED TO CIRCUIT P8-24. UNDER BID ALTERNATE N0. 1, THESE (2) RECEPTACLES AND SURFACE WIRING SHALL BE REMOVED. FLOOR PLAN - RENOVATED ELECTRICAL SCALE: 1/8" = l'-0 T /� 113 WEST MAIN STREET S T R I C L L� JACKSON, MISSOURI 63755 E N G I N E E R I N G FA 573-243-4080 FAX: 573-243-2191 CIVIL - IvICLHANICAL - ELECTRICAL ENGINEERING - LAND SURVEYING DATE: 03/12/09 PROJECT: A.C. BRASE ARENA SHEET: 4 OF 8 BUILDING RENOVATION PROD. NO. 08-115 CAPE GIRARDEAU, MISSOURI DESCRIPTION: E1.3 NEW SURFACE WIREMOLD WITH 20A GFI DUPLEX RECEPTACLES FOR FOOD SHOW USE (TYP.) ENCLOSE EXPOSED FLEX CONDUIT IN WIREMOLD. MP LP5 T 1(h . 4 ROUTE FEEDERS TO MP ABOVE CEILING TO MP. ROUTE FEEDERS TO MP ABOVE CEILING TO MP. s - CANOPY COLUMN VERIFY LOC. 7 911 13 15 AN, li .IJ. ,u u 18 NEW SURFA( 20A GFI DU FOR FOOD 16 14 12 % d% 8 TO TRANSFORMERS SMP I� 12"x12" J_BOX (MIN.) L J Irr LP5 1CORE DRILL FOR 4" � GFI CONDUIT TO J—BOX BID ALT. NO. 9 LP2 EXISTING SURFACE MOUNTED 120/24OV, 1—PH PANEL, REMOVE INTERIORS AND FEEDER CONDUCTORS. INSTALL A NEW COVER ON BOX FOR USE AS A PULL BOX FOR WIRING EXISTING CIRCUITS THRU BOX TO NEW PANELBOARD LP2. INSTALL INSULATED TERMINAL BLOCKS AS SPECIFIED AT ELEV. 100'-6" OR HIGHER. NEW 200 AMP PANELBOARD LP2, 200 AMP, 120/24OV, 1—PH, 3—WIRE, 42 SPACE. MOUNT BOTTOM OF PANEL AT ELEV, 100'-6" OR HIGHER. NEW 37.5 KVA TRANSFORMER WITH 48OV, 1—PH PRIMARY AND 120/24OV, 1—PH SECONDARY WITH FEEDER TO LP2. MOUNT TRANSFORMER ON WALL BRACKET WITH BOTTOM OF TRANSFORMER AT ELEV. 101' OR HIGHER. CORE DRILL THRU CONCRETE WALL FOR FEEDERS, TYP, TUNNEL PLAN - RENOVATED ELECTRICAL SCALE: 1/8" = i'-0 T T , N 113 WEST MAIN STREET R S T "" C K A y" D JACKSON, MISSOURI 63755 E N G I N E E R I N G FA 573-243-2191 FAX: 573-243-2191 CIVIL. - MECHANICAL - ELECTRICAL ENGINEERING - LAND SURVEYING DATE: 03/12/09 PROJECT: A.C. ERASE ARENA SHEET: 5 OF 8 BUILDING RENOVATION PROD. NO. 08-115 CAPE GIRARDEAU, MISSOURI DESCRIPTION: E1.5 LIGHTING FIXTURE SCHEDULE MARK MANUFACTURER MODEL NO. DESCRIPTION LAMPS BALLASTS FINISH MOUNTING A METALUX 2GC8-332A-120• 2'x 4', 3 -LAMP FLUORESCENT (3) 32 WATT (1) 120 VOLT WHITE RECESSED IN EB81 RECESSED GRID FIXTURE WITH T8 LAMPS ENERGY SAVING CEILING GRID AT ACRYLIC LENS ELECTRONIC LOCATIONS SHOWN BALLAST Al METALUX 2GC8432A-120• 2'x 4'. 4 -LAMP FLUORESCENT (4) 32 WATT (1) 120 VOLT WHITE RECESSED IN E881 RECESSED GRID FIXTURE WITH T8 LAMPS ENERGY SAVING CEILING GRID AT ACRYLIC LENS ELECTRONIC LOCATIONS SHOWN BALLAST 8 HALO M20OT-730-21G RECESSED METAL HALIDE (1) 70 WATT (1) DUAL -TAP WHITE RECESSED IN DOWNLIGHT FIXTURE W/ METAL HALIDE METAL HALIDE CANOPYAT 10.1/2" SQUARE APERTURE LAMP BALLAST LOCATIONS SHOWN & FRESNEL LENS C INVUE VXM-400-MH-480 METAL HALIDE POLE LIGHT (1)400 WATT (1) 480 VOLT TO BE POLE MOUNT AT 5S-xx-L-MA1O50-xx FIXTURE W/ TYPE V DISTRIBUTION METAL HALIDE HIGH POWER DETERMINED LOCATIONS SHOWN LAMP FACTOR BALLAST SEE NOTES 4 AND 6. 0 INVUE VFM-K-250•MP- METAL HALIDE FLOOD LIGHT (1) 250 WATT (1) 480 VOLT TO BE POLE MOUNT AT 480-WF.xx-L FIXTURE W/ MEDIUM SPREAD METAL HALIDE HIGH POWER DETERMINED LOCATIONS SHOWN LAMP FACTOR BALLAST SEE NOTES 5 AND 6. E SURE-LITES RLM2 RECESSED, DUAL HEAD EMERGENCY LIGHT (2) 9 WATT --.•- WHITE RECESSED IN WITH LEAD CALCIUM BATTERY FOR LAMPS DROP CEILING AT 90 MIN. OF EMERGENCY OPERATION LOCATION SHOWN. F LUMARK MHIP-T-100-12OV- METAL HALIDE WALL PAK (1)100 WATT (1) 120 VOLT TO BE WALL MOUNT ON PE -LL FIXTURE WITH GLASS LENS METAL HALIDE HIGH POWER DETERMINED BLDG EXTERIOR AS AND BUTTON PHOTOCONTROL LAMP FACTOR BALLAST SHOWN ABOVE GRADE. _ VERIFY HEIGHT W/ G LUMARK MHIP-TM400A. METAL HALIDE WALL PAK (1) 400 WATT (1) 120 VOLT TO BE ARCHITECT. WALL MOUNT ON 12OV-PE-LL FIXTURE WITH GLASS LENS METAL HALIDE HIGH POWER DETERMINED BLDG EXTERIOR AS AND BUTTON PHOTOCONTROL LAMP FACTOR BALLAST SHOWN ABOVE GRADE. VERIFY HEIGHT W/ X SURE-LITES LPX70RWH LED EXIT LIGHT FIXTURE W! RED LED ARCHITECT. POLYCARBONATE HOUSING AND --- WHITE CEILING MOUNT NICKEL CADMIUM BATTERY FOR ABOVE DOOR AT 90 MIN. OF EMERGENCY OPERATION LOCATION SHOWN. LIGHT FIXTURE SCHEDULE NOTES: I. ALL FIXTURES SHALL INCLUDE SHIELDING AND GASKETING TO PREVENT LIGHT LEAKS. 2. ALL FLUORESCENT LAMPS SHALL HAVE A COLOR TEMPERATURE OF 4150K. 3. ALL INCANDESCENT LAMPS SHALL BE RATED 130 VOLT. 4. 25' POLES FOR ALL TYPE'C' & TYPE'D' LIGHT FIXTURES SHALL BE EQUAL TO INVUE #SSX5A25SxxM1 WITH 1 SIMPLEX FITTING MOUNTED 20' FROM BASE @ 180- FROM THE HAND HOLE. SEE MANUFACTURER'S SHOP DRAWINGS AND DRAWING E1.5 FOR MORE DETAILS. 5. MOUNTING BRACKET FOR FLOOD LIGHT FIXTURE SHALL BE EQUAL TO MCGRAW PART#109W14. MOUNTING BRACKET MUST BE ORDERED WITH POLE. 6. COLOR FOR POLE MOUNT FIXTURE. FLOOD LIGHT FIXTURE, AND POLE TO BE DETERMINED BY OWNER. Mm Offig I.&rwf I - - - - - - - - - - ..� . . . . . . . . . .......... ;," iff 2-�L- L-1 S T R I C K T N ') 113 WEST MAIN STREET 1J v L JACKSON, MISSOURI 63755 E N G I N E E R I N G TEL: 573-243- ® FAX: 573-243-21912191 L-IVIL LLLC I RICAL ENGINEERING - LAND SURVEYING DATE: 03/12/09 PROJECT: A.C. BRASE ARENA SHEET: 6 OF 8 BUILDING RENOVATION PROJ. NO. 08-115 CAPE GIRARDEAU, MISSOURI DESCRIPTION: E1,8 REMOVE EXISTING LIGHT 400 WATT WALL PAK A FIXTURE TO OWP CONDUIT & WIRING AND I INTERIOR TO EXISTING ARENA BUILDING NORTH WALL ARENA BUILDING SOUTH WALL TR I 113 WEST MAIN STREET A- JACKSON, MISSOURI 63755 EN G FA I N E E R I N G 573-243-4080 FAX: 573-243-21912191 �_Ivll_ - rlctrlAlviLAt - I-LLC7RICAL ENGINEERING - LAND SURVEYING DATE: 03/12/09 PROJECT: A.C. BRASS ARENA SHEET: 8 OF 8 BUILDING RENOVATION PROJ. NO. 08-115 CAPE GIRARDEAU, MISSOURI DESCRIPTION: E1.8 1, THIS PANEL SHALL BE EQUAL TO A SQUARE'D' TYPE 'NQOD' PANELBOARD WITH TYPE'QOB' BRANCH BREAKERS. 2. THE FEEDER TO THIS PANEL FROM NEW PANEL'DP1' SHALL INCLUDE (1) 2" CONDUIT WITH (3)#3/0 THWN/THHN CONDUCTORS AND (1) #6 GROUNDING CONDUCTOR. SEE RENOVATED ELECTRICAL RISER ON DRAWING E1.6. 3, CIRCUITS NO. 1 THROUGH NO 12 ARE CURRENTLY FED FROM OLD MAIN PANEL. THESE BRANCH CIRCUITS ARE TO BE PULLED TO TERMINAL BLOCKS IN OLD MAIN PANEL PULL -BOX, INSTALL DIVIDER IN PULL -BOX TO SEPARATE THESE BRANCH CIRCUITS FROM THE BRANCH FEEDERS FROM PANEL DP1. 4, VERIFY CIRCUITS NO. 1 THROUGH NO. 12. SCHEDULE SHOWN IS TAKEN FROM EXISTING OLD MAIN PANEL SCHEDULE. 5, VERIFY CIRCUITS REQUIRED FOR NEW GENERATOR. INSTALL CIRCUITS NO. 13 THROUGH NO. 18 TO GENERATOR ENCLOSURE IN 1" CONDUIT TO A 12"X12" J -BOX. VERIFY LOCATION. CONTINUE BRANCH CIRCUIT WIRING FROM J -BOX TO REQUIRED TERMINATIONS AS REQUIRED. PANEL 'LP1' 120/240V, SINGLE PHASE, 3 -WIRE, SOLID NEUTRAL 225 AMP MAIN LUGS ONLY, SURFACE MOUNT CIR. NO. BRK. SIZE NO. OF POLES WIRE SIZE SERVES VA PH VA SERVES WIRE SIZE NO. OF POLES BRK. SIZE CIR. NO, 1 20 1 12 2ND FL LIGHTS A KITCHEN RECEPTS 12 1 20 2 3 20 1 12 VERIFY B VERIFY 12 1 20 4 5 20 1 12 MAIN MTG RM A ELEC. RM LIGHTS 12 1 20 6 7 20 1 12 N OVERHEAD DR B DINING ROOM 12 1 20 8 9 20 1 12 RECEPT. A EXIT LIGHT 12 1 20 10 11 20 1 12 2ND FL OFFICE B KITCHEN LIGHTS 12 1 20 12 13 20 1 10 GENERATOR A GENERATOR 10 1 20 14 15 20 1 10 GENERATOR B GENERATOR 10 1 20 16 17 20 1 10 GENERATOR A GENERATOR 10 1 20 18 19 20 1 10 RECEPTACLES B RECEPTACLES 10 1 20 20 21 20 1 10 RECEPTACLES A RECEPTACLES 10 1 20 22 23 20 1 10 RECEPTACLES B RECEPTACLES 10 1 20 24 25 20 1 10 RECEPTACLES A RECEPTACLES 10 1 20 26 27 20 1 10 RECEPTACLES B RECEPTACLES 10 1 20 28 29 20 1 SPARE A SPARE 1 20 30 31 20 1 SPARE B SPARE i 20 32 33 SPACE A SPACE 34 35 SPACE B SPACE 36 37 SPACE A SPACE 36 39 SPACE 8 SPACE 40 41 SPACE A SPACE 42 bnr.iei C+lLICn1 t- w TOTAL CONNECTED LOAD = 0 VA 1, THIS PANEL SHALL BE EQUAL TO A SQUARE'D' TYPE 'NQOD' PANELBOARD WITH TYPE'QOB' BRANCH BREAKERS. 2. THE FEEDER TO THIS PANEL FROM NEW PANEL'DP1' SHALL INCLUDE (1) 2" CONDUIT WITH (3)#3/0 THWN/THHN CONDUCTORS AND (1) #6 GROUNDING CONDUCTOR. SEE RENOVATED ELECTRICAL RISER ON DRAWING E1.6. 3, CIRCUITS NO. 1 THROUGH NO 12 ARE CURRENTLY FED FROM OLD MAIN PANEL. THESE BRANCH CIRCUITS ARE TO BE PULLED TO TERMINAL BLOCKS IN OLD MAIN PANEL PULL -BOX, INSTALL DIVIDER IN PULL -BOX TO SEPARATE THESE BRANCH CIRCUITS FROM THE BRANCH FEEDERS FROM PANEL DP1. 4, VERIFY CIRCUITS NO. 1 THROUGH NO. 12. SCHEDULE SHOWN IS TAKEN FROM EXISTING OLD MAIN PANEL SCHEDULE. 5, VERIFY CIRCUITS REQUIRED FOR NEW GENERATOR. INSTALL CIRCUITS NO. 13 THROUGH NO. 18 TO GENERATOR ENCLOSURE IN 1" CONDUIT TO A 12"X12" J -BOX. VERIFY LOCATION. CONTINUE BRANCH CIRCUIT WIRING FROM J -BOX TO REQUIRED TERMINATIONS AS REQUIRED. Zoellner ConstructionCo., inc. 675 PCR 500 • PERRYVTLL.E, MO 63775 • 573-547-8030 • PAX 573.547-8034 '1'0: CON(WANY; FACSIMILE TRANSMITTAL SHEET DATE: TOTAL NO. OF PACES INCLUDING COVER: FAX 'NUMBER. OUR FAX NUMBER; 573-547-8034 PHONE NUMBER- OUR PHONE NUMBER; 573-547-8030 Q Urgcnt 0 For Quotc C7 Please Comment O Please Reply 0 Plegst RccYcic t V ., "( :l )?i" Ii 1 t I Gentlemen, Schneider Electric Co., with offices in St, Louis, Jefferson City, and Southeast Mssouri, is a full service electrical contracting company. Schneider Electric specializes in Industrial, Comyne�•Cia1, Institutional and Line Electrical construction. With over 100 dedicated employees, Schneider Electric can meet all your electrical contracting needs. Schneider Electric Co. has been serving the Missouri area for over 50 years and has been included in ENR magazines list of the top 600 "Specialty Contractors" for the past nine years. With our years of experience and expertise in both Design/Build and Plan & Spec, projects we will provide you with the best in value, safety, and workmanship for any projects you may have_ in the past 25 years we have completed well over 2000 projects, including many large Industrial projects and over 30 hospital projects. We value the long lasting relationships tive have developed with Owners and General Contractors. We would like to add your name to our list of satisfied customers. Please review the enclosed information about our company and feel fi ee to call me if you have any questions or conccm5. Sincerely, Robert J. C.Tnterreiner P.E. President rmgder sled is Company s�1s Evotin� �aL tdul6, MO 62128 (314) 6445' 7M FAX (314) 844-4739 Schneider Electric Company I;Iectricai Contractors St. Louis —Jefferson City SUBCONTRACTOR PREQU ALIFICATION QUESTIONNAIRE Please complete questionnaire and attach additional information for other locatlons as necessary. 1. WORK EXPERIENCE Scope of Works Performed x EngineeringiQesign Construction Management x Construction f Erection _ PreNbdcation Capabilities Types) _ Procurement -- Equipment _ Procurement - Commodities Other: Type of Work: Date: January 2, 2007 Company_ Schneider Electric Co t (Do not include work that you subcontract) Contact. Robert J. Unterreiner Title: President Street Address: 6115 Eveline St P.O. Bax: _ Underground Piping & Utilities x City: St. Louis City: Electrical Statelzip: Missouri 63139 -- Stateizip: Equipment Erection Phone: (314) 448-4701 Fax: (314) 446-4702 E -Mail: runterreiner@schneiderelec.com Web Address: Preferred address for sending bidpaG(ages Prefarred addmss for updetintg data: Con=tact: CreR Graham Contact. Bots Unterreiner Title: Chief Estimator Title: President Address: 6115 Eveline St Address; 6115 Eveline St _ X Refinery St Louis, MO 63139 St Louis MO 63139 Phone: 314 446-4707 Phone: 4(3� 44r:.,-4701 _ Pax: (314) 644-4738 Fax: 314 644-4738 E -Mail; ggrahgmQschrreiderelec.ccm E -Mail. runterreinetr_ nBidereleC.Cor13 1. WORK EXPERIENCE Scope of Works Performed x EngineeringiQesign Construction Management x Construction f Erection _ PreNbdcation Capabilities Types) _ Procurement -- Equipment _ Procurement - Commodities Other: Type of Work: Please indicate approximate percentage each type of wort: represents of your total wort_ t (Do not include work that you subcontract) EarthworktSitewofk Piping _ Painting a Special Coatings _ PiiinglDrilled Piers _ Mechanical _ Heat Treating _ Underground Piping & Utilities x instrumentation _Catalyst Handling Foundations & Concrete Paving x Electrical _ Asphalt Paving Structural Steel Erection Thermal tnsulati❑nIFIreproofing Equipment Erection _ _ tire -engineered Metal Buildings _ Refractory Other I Percent of worsts Subcontracted: '/o Construction Equipment: Own Rent _ Both X _ if Moth, please specify: _ Own LO% r Rent 30% j Plant/Work Type Experience X Chemical Powerhouse _ Other (Specify Type) _ X Refinery Coil X Water Treatment X Gas i X rower, Transmission Line X Coal X Telecommunications X Nuclear PGN•304D (Rnfsrsnced EEC -Std -2-t 0G%-00001) i 1 Page i of 4 Schneider Electric Company Electrical Contractors St. Louis — Jefferson City i i SUBCONTRACTOR --REQUALIFICATION QUEST10NNAIRE I I I 2. ORGAN17-ATION Years in Business 24 Tax ID # 43-1249816 Company is legally established as: X Corporation State of Incorporation: Missouri Partnership Partners: Joint Venture Partners: Proprletorship Owner_ Other-. Specify: Date: February 17,1982- Is 7,1982 Is Company owned or controlled by a parent company? Yes X No Legal Name of Parent Company: Full Address of Parent Company: Relation►'hip to Parent: Key Personnel President: Vice President Engineering Manager. Construction Manager: Contract Manager: Quality Control Manager: Safety Manager - Total Number of Employees If yes. complete the following; Subsidiary Division Elate of Ownership Name Ruberl:J.Unterreiner P -E. Robert J. Unterrelner Greg Graham _Jamie L. Lancaster Steven Schisler Steven Schisler 20 Horne Office Attach Qualifications 110 Field Utilizing Business Classification as defined by U_S. Government agencies, Company certifies that its Classification is: Large Small Disadvantaged Wornan-owned Business X Business Business _ Business _ Does your company operate as X Union Open T Both Does your company operate under a national labor agreement? X Yes No If yes, explain: National Maintenance Agreement -- -- Does your company operate under any local labor agreement? X Yes � No If yes, explain' (_B.E.W. Locals 1 2 257 Has your company been Involved in any tabor disputes vdthin the past 5 years? _ _ Yes X No If yes, explain: Is your company a member of any contractors association? X Yes No If yes, explain- National Electrical Contractors Assn, American Subcontractors Assn PGN-304D (Referenced EEC -Sid -2-00615-00409) Page 2 of 4 Schneider Electric Company ` Electrical Contractors St- Louis -- Jefferson City SUBCONTRACTOR PREQUALIFICATION QUE$TIONNAIRE 1 3_ FINANCIAL DATA Total Work in Progress or Under Contract Average Annual Construction Volvrne (Last 5 Years) Attach Audited FInandai Statement Current Assets: $ 1$26,659_ Current Liabllltles $ 2.73P,036 $ 9.534.819 2005 $ 21,159 729 2004 $ 19,296,606 2003 $ 17,901_756 2002 $ 20,428.553 2001 $ 16,811,455 Project Size Capability_ X Less than $10,000 X $1,000,00045,000,000 x $10,000-$26,000 $5,000,01)0-$95,000,000 X._ $25,000450,000 $15,000,000-$25,000,000 X $50,0004500,000 _ p25,000,000-$50,000,000 X $500,001741,000,000 Greater than $50,000,000 4. BANK REFERENCE Bank(s) Maintaining Account(s) Enterprise Bank Contact Name Chuck Leuck Phone: 636 926 -3900 S. BONDING Capacity $ 10,000,1)00 Banding Company International Fidelity Phone: Contact Name ISU SL Charles Insurance Phone: (636) 477-0500 6. INSURANCE Attach C�rtifcmte of Insurance Name of Insuring Company ISU St. Charles Insufance Phone_ (536) 477-0500 Contact Dame Steve Ruff Phone_ (636) 4770500 7. GEOGRAPHICAL RADIUS OF OPERATIONS X Local - portion of Stag: >=astam , Southeastern & Central Missouri Ragional - Which States: National - All States International — Countries: S. QUALITY SYSTEM Attach Quality_ Control Manual and/or ISO Certificate Is your company ISO certified? _ Yes X No If no, do you have a documented quality system in place? Yes X No If requested, would you permit access to your faciiiFies for inspection or audit? X Yes No PGPt'p (ReferErrd EEC Std-fl57�=D6101j PNe3of4 Schneider Electric Company Electrical Contractors St. Louis — Jefferson City SUBCONTRACTOR PREQUALIFICATION QUESTIONNAIRE PLEASE ATTACH THE FOLLOWING INFORMATION: • Listing of work currently under contract, including name, location, amount, client and reference or contact • Key personnel qualifications • Most recent audited financial statement ■ Insurance Certificate j . Quality Assurance Manual -uncontrolled copy - (including second tier inspection and testing procedures and work instructions if they are separate from QA manual) b Safety information as requested on the Safety and Health Program Questionnaire Including, EMR for the last 3 years on your insurance carrier's letterhead OSHA logs for the last 3 years Safety and Health Program (Cd or Diskette if possiblo} • Sales and Marketing Eroohures PGM-IN40 (Refarencad r -EC -Std -2-00515-100001) Page 4 of 4 M..amh 19,200-0 Zoellner Construction, Co. 875 FCR 5O0 Perryville, MO 63775 Steve, Per your request here is a list Of gePerators installed in the last five years LOCATION SIZE OSA Data Center for USDA St. Louis 750 KW Bob's Creek Waste water Treatment Plant Troy, Mo. 500 KW Duckket Creek Pump Station O',Fallon, Ido. 500 KW Highway DD.PWnp Station O'Fallon, l4'o. 504 KW St. Cbarles Puaxap Station St. Charles, Mo. 600 KW If you reed any additional info Mation please call. Sincerely, Bob Un,terreiner President 6115 Evalna .4.eui�� flfQ tS3139 (3143 50#� Q7Uq X (ass} 644-4738 M- W 1� LO N CD M LO N A CDM b r. M CD m N U, Partlnt List Work in Process 06/15105 Proiect zt With CaniTict tlmaimt perc�ent Comt�le#e Mernmee W.W.T.P, Metropolllan Sevier District GoodrrinBros $6,450,000.00 65% New W.W.T.P. 8t. Louis, kNIO Boone I•Ioslsilal Center Boone Hospital Roane flospitol $4,116,000.GO 9D% New Service C4h►mbia, MO Mis3013ri Baptist I•Iasnital Sullivan, xfo Murray S 643,000.00 95% NewI-Impilttl Wiitg 3eMrson City Correctional State ofMissourl Stnte of Missouri $1,772,000.00 95% Perimeter Security Jefferson City, MO x1a R Foods Columbia Kxaft roods Kraft Foods $1,000,000-00 Ongoing Esc Projccls Coiaimbin, MO Duckett CmCL W-W.T.11 City ofO'Palton Tarlton S 499,318.00 1600/0 New VIWTP O'Falian, MO O'i?allon W.W.T.P. City occ'Fallan Goodwin Bros. T 578,750.00 95% New WWTP OTallon, tufa Ciayion City ITali City of Claytoll BSI Const«ictors $ 615,000.00 95% NetivAdditian Clayton, MO Kingsfard CLarcoll Kingsford Kingsford $ 600,000.00 Ongoing Mise Pro}cels Belle, MO Melrolink Bi -State Development Tnrllan 57,750,000.00 5cp�a Light haft St. Louis, MO M- W 1� LO N CD M LO N A CDM b r. M CD m N U, J Lt1 01 J 07 0 W A I -0 D G) M CD LD N 01 rartial List 1n[11.lstriAl References Ftt�iect D►t�ter Contract Wiih EnGineer Contr,ct Amotbnl Metropolilan Server District M.&D. Kloster Con.stnlction Black & Veatch $1,587,436 LOMT River Des PeIC& Bri;ul I'TocIsdcr Rick Crcbel Scan Rahr Pump Statians �C Owe Modifications (314) 768-6377 (3H)8A-8888 (314) 532-7940 Union Elcclrlo Campany Union Electric Co. Union Electric Co. Union Electric Co. $ 954,831 Labadie Potver Plant Joe Rinke Charlie 1:ronick John Shodduck Controls Upgrade (314)554-26162 (314)992-8424 (314) 554-3075 Sioux 1`11111 AntcranUla 13.hl6crici AireranUE $1,950,000 Coni Conveyor Doug Korte Dan Randolf (314)261-2611 AtneranUlr AmeranUE NfcCarthy Construction PC&E $ I,?S(},oOD Memmec Power Plant Joe Rinke Tom Felton Control Upgrade (314)55,1-26162 (314)968-3300 United Sitties postal Service U, S.P.S. U.S.P.S, Li6morSammars i`mac 51,075,000 Main Post Office I -M Carlen Ern Carlen Jinn Latimer Repiace Stvitchgaar (}13)261-2433 (M)261-2433 (785)233-3232 �imaratlttJl's rintcr,�rii3li iUiccifil y 7'C�&�i 1,49R,0DQ Bust Suppression Joe Rinne (314)58 1-?6GZ (314)963-3300 Mallincicrpclt tAnllirtckradL Rhodcy & San Lockwood Grccne 51,5&6,000 Varfnus Mikc Cnpculi St. Lon is, 1410 (314)521-0022 Nuell Point M.SM. Tarlton Havens &-- Emerson $1,769,040 Wnste Water Trealmcnt Pinnt i4lanBoyce St. Louis, i4ifl (314)647-6000 J Lt1 01 J 07 0 W A I -0 D G) M CD LD N 01 (/s�t LO LO N CD CD LEI A m Un w Ln A v CO CDW A 0 M F F z `m m 0 0 z cn M N 0 4 Pirthil List Commei-chd References Project Q�t21er Contact With Engineer Contract Amount Pnttonvilie High School Please I Peitonvillc School S.M. Wilson Parsons Brinkerhof 53,904,000.00 Renovations District Adam Fark SchacI v-, Comm Ctr SL Louis Public Schools S. M. Wilson 7. Kent Denton $1,582,000,00 New School & Comm. Canter Home Depot I10rma1)apot S.M. Wilson Casco 51,082,000.00 New Stara Chesterfield Commons TI -IF Realty I -G. Brinkrnann TU A.rkitects $1.570,000.00 New Strip Mal l Nance E[ententnry Sehooi St. Louis Public Selicols K&,S tlssaciates G & W Engineering S 960,425.GO Nese I:icmentriry► School Employntcitl S"Ildly Slate afMissau i Prost Builders Kuhlman Design Group 31,064,000.00 Ltlerior I?.ruovalions Finrrnit'sI•Iotel florrahs WaIton Const iJnccidcrBIccbric Co. 51,261,000,00 Renovalion Target Sion, Colunlbin Torl et I.13D coalmuling Target S 410,000.00 Remodel PnttonvilIv School Dirtricl Mose II f+,ittonville School S.M. Wil!IWI Porsons Brinkcrliaf $11,150,000.00 Maryland Aventie Garage Univi,rsity of MissGod I'ru-Coll Kuhlman Design Group 660,000.00 New Parking Gangr UIv15L University of Nf.issotiri K.C.I. Kennedy 3 llS ,000.0a i,�" SAI. • New Parking Garage (/s�t LO LO N CD CD LEI A m Un w Ln A v CO CDW A 0 M F F z `m m 0 0 z cn M N 0 4 Partial List Water Treatment References Proi-pct Owner Conlnet Whit Fnaineer Contract amount Melrapalitan Se}vier District Kloster Construction Black & Vcntch 54,887,436 Lower River Dcs Peres Brian Hoelscher Rick Grebel Sean Rohr Pump Slntions & Gate Modifications (31 1) 768-6377 (39+1)891-8888 (314) 532,7940 Bissell Point ?Yt.S.D. Tarlton Havens & Emerson $1,769,000 Wade Wafer Tr-ntmcnt Planl St. Lauis,MO (314)633-3300 Chain OfRoclts City of St. Louis Tnrlion Purac. Engineering S 45,048 Presedimen lallottlGrit Basins Matt Phunti Wilmington, DE & Softening Basin Improvements (314)633-3340 (302) 996-0545 Grand Glaizc Iv1.S.D. C.C.I. Construction Consoer'rowsand S 362,000 Sludge rnprovernews hick Grebel (311) 394-3838 Moberly W.W.T.P. Ci€y of Moberly IvAnbilt Construction MCCO Engineering 5 370,549 Wnstewnter 7m ihttent Clrilicodice, NIO Kiefer Greek M.S.D. Goodwin Bros Havens &, Emerson S 368,000 New pit nip Station .Pesttts, MQ Vonae Road M.S.D. Goodwin Bros I.lnveus & Emerson $ 412,545 New rump Station vastus, MO Rolla W.W.T p Cily nCRnttn, ?VIO Robinson Construction Ross S-, Darruzini S 485,60D S ,mMewiWrTreniment Perryville, MO Mefamec W.W.T,P. MSD Goodwin Bros CM211 IIill $6;150,400 New W.W.T.P D, CJ Lu nJ 0 M ua N r. CD CD Ln _._, 03 01 —, N W M N Un Partial List Linetivork Refarences Proiert Owner colltme With Coma Dale Contract Ar 00131 _ Primary Line & Taps U.S. Depirtment Gu3rantec Electric 1998 $127,000 At CSS Production FaciIit r of Energy Weldon Springs LCRS Termination Pole US. Department Guaranwe Vearie 612.000 S 5,000 Weldon Springs Distribution Line & City Of 0wCTISVlll4" City of Owensville 711947 $303,900 Stibstaation ModiJications missomri Missouri Line Claangff &.Transformer • Phillips Pipeline Phillips Pipelin, 212000 S 24,000 Replacement Woad River IL Wood River IL Wimayry Conduits S. Gratin cling J%mcranUE AarmcmaM 611999 26,040 Ofallon Hills Substation Conlrol Conduits & Grouneling Ame nnLTE ArncrnttUE 417-00I s 17,000 Ofaallon I•illls Substation Partial List High Voltage & Substation Refermcs Project Owner Contract With ringimr ContLme Imunt rvtatrapolUnnSevmrDistrict ivf,&DT I lomtcrConstruction 131ack&Veaten $4,887,436 Lower River Des Peres 12.8kv Distribution UnIled Slates Postal Service U.S.P.S. U.S.M. LatimerSonuncrs &Assoc $1,075,000 St. Loin s, MO Replace SwVilchgear Wasli U Throop Drive„ won hington Univ 'Tarlton McClure S 421,370 St. Louis. MO Electric Stibslation Men. mee Pulver Pinnt AtnetcnUE AmererPUE AmeranUE S '?75,000 St. Louis, MO St1bblion 'Regittce 13Skv13rkr Stoddard County Substalion AmcrenUE AmcrenUE AmcrenUE S 511,000 Sikestcn, mo Reworked'011 Lines S, Switches Sioux Power Plant AmcrcnUr; AmcrenUC ArncrenUl; 3 31,400 West Alton, Mtn 138b, Breaker Wasit [1 Medimi 5ubslnlion hmcrrnUE AmcrcnTJl; limercnUl 93,200 St. Love 'q' MtJ ltel�lace 'l'rn��s fors ner Labadie Power Plant AmcrenUr— AmcrenUE AmerenUE 51,600 Lnbadic, MU 0enc, rntor?Trana Former w St. Charles Insurance 4500 Executive Centre parkway Suite D St. Peters, MC 53376 636-477-0500 Fax 638-177-0600 January 26, 2007 To Whom It May Concern RE: K Tech Corp. DBA Schneider Electric Co. Experience Modification History To Whom )t May Concern: Please find below experience rnodificatian history for the last three years. 01/0112007 _84 0 110 1 /2006 .83 01/01/2005 ,94 01/01/2004 .96 If you have any questions or treed any additional information, please feel free to contact our office. Thank you. { f► �f - 1% Steve Ruff Account Executive E-mail address: stevexuff@stcins.corn . 4 CERTIFICATE OF LIABIL 7-0-1111((635) 47 7 -0500 FAX (636)577-0600 ' St. Charles �n5ur�3scJa 4600 Executive Contra Parkway i wi to 1 St. Peters, MO 63376 I wnm K TeCh Corp - DBA: Schneider Electric Co. j 6115 Eve? i ng St. Louis, MO 63139 I } ACORD 26 {20U11t0S) ITY INSURANCE o1/2; 2oc7' THIS CERTIFICATE 15 ISSUED AS A MATTER OF INFORMATION ONLY ANI] CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER, THIS CERTIMATE DOM NOT ANIEND,1_XTENO OR A ER THE COVERAGE AFFORDED SY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NAIC 4 JAISLJRERA: AMERISUPE INSVR=n a INSURER C� INSURER a: iMSURER E 4:VV L�C� �p� THE POLICIES OF INSURANCE LISTED BECOW HAVE SE=EN HUED To THE INSURED NAMED AE VE FOR THE POLICY PERIOD IPIDIGATEO.140TVVITKSTANDING ANY REQUIREMENT, TErRM, OR CONDITION or ANY CONTRACT OR OTHER DOCUMEUT WITH RESPECT TO WHICH TWIS CERTIFICATE KIAV SE ISSUED OR ?AjkY PERTAIN, THE It�F"aURANCEAFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT To ALL THE TERMS, EXCLUSIONS AND COUDITIONS OF SUCH POLICIES. AC{3nGATE LIMITS SHOWN MAY HAVE BEEN A40UGED SY PAID CLAIMS. TNSR D TYFB OFfNSVRAtit6 pGUGY NUMlifiR ?inuc &FFEGTIVE POLICY E%PIRATICIN LIMITS 30 C'AY9 WMITEN N0-nr-L TQ TKE CEq—,a CAT-` rMI7ER NAAIEM TO THP LSr'T. GENERALUADLUY CPP2034177 11/30/2006 11/30/2007 2ACHOCCURRENCE s 1 000,00 DAMAGE TO PEN S 30D 00 X COMmEACrFL ¢EDYRAt LIABILITY MEO EX"r'tAny er+e 15"Sm) 5 10,000 CL.R:IS p,AE)E 510- l ^ I PpROQNAL e. ADV NJURY S 000,000 X XCU GEFF_RAL AGGREGATE S 2_00 00 GE KT L, AGGTMGATH VMfT AFFUrS PER; PRODUCTS .COW -*P AGG S 2 Q w LIO I—] POLICY 7d CDT" LOG AUTOMOBILE UAFM= CA2034176 11/30/2006 11/30/2407 C0y111,NEGgNGLE LI1.9T s x ANYAUTO (E�gaidEMl C}00,00 VontLY tfuLIRY s Att CAVNEDAUTOS (Perparsan> A X SCaEOULOO1.UTas HIREDAUTOS 20MY IAJJURY S X NDN-0>R4dE0 AUKS (Her g11j PROPERTY OMIAGE $ GARAGE LIABILITY AUTO DNLY - EA ACCIQENT S OTKER TM,%N FA ACC 5 ANY AUTO AUTO ONLY: AGG S EXrESSAJPASREL, A LIA9IUTY CU2034180 11/30/2006 1/13012007 FACH OCCURRrt,= s S 000 O0 AdGREGaT; S 5 ()00,00 X OCCUR CLJtldiEMAUE ,� fe Rfr1r;k iT8LP XRETtTtGM 5 tiRtsrzsco�a;nlsaT.tirtaNJ� Wt2034Z$3 A313U/Z006 11/3012007 X w+FST,�TU- E.L. EACH ACCiDEPR s 540 b00 EMPLO'e0cr LIAGIL.iTY A ANY PROFfPEtORIPARTNXBCLfT1VE 0FnCEPVMCt•IE6.1 Vf LUDEn7 C.L. MC-A.SE - EA EMPLOYE S 5OU 40 Wdetvtw wdar SPECIAL PROVISIONS �M*w E.L. USCASE- POLICY LWIT 1 S 500,000 inland Ft rine CPH2O34177 lij3O/2005 Zi 30/20117 $100,000 Limit per -item A n5ta11Dtion Floater BR S600,001) Limit (Floater) QESCRJPTIQNQFOPERATIONSrI_QCAT StVENICLE57SYCLV811�N9ADL'EO9YENDORSLMENT!SPECIALT'FIOV1$1PN5 !^A Air 011 ATIr)NI {QACORD CORPORATION 1989 SHOULO ANY OF THE ABOVE DESCR16CG PGLICreS EE CANCELLPS BEFORE THE BXPiPAMn =TE THEREOF, THE [SS -LANG INSURM WILL ENDEAVOR TO I,IAiL, 30 C'AY9 WMITEN N0-nr-L TQ TKE CEq—,a CAT-` rMI7ER NAAIEM TO THP LSr'T. BUT FAILURE TO MAIL SUCH 1`40TICE'aWA0, IMPEMr NO OBLIGATION OR UAQIUTY OFAN'f POND UI VU THE 105URI-M,;n AgWKTS OR REPRESENTATIVES. �"7ATw£ Ste tT�r. f €2tlf13RIANC �" To Whom it May ConCern {QACORD CORPORATION 1989 IMPORTANT if the certificate holder is an AI)Dt T ZONAL INSURED, the policy{ies) must be endorsed, A statement on this certiriicate do�-s not confer rights to the certificate holder in lieu of such endorssment(s). if SUBROGATION IS WAIVED, subject to the terms snd conditions of the policy, certain policies may require an endorsement. A statement on this certmcate does not enter rights to the certificate holder In lieu of such endorsement(s). DISCLAIMER T-ne CertifiGate of Insurance on the reverse side of this Form does not constitute a cwtrect between the issuing insurer(s), authorized representative or producer, and the certificate holder, not does it atiirmatfvely or negatively amend, extend or atter the coverage afforded by the policies listed thereon. ACORD 26 (200VOS) i i ' Me. Untcrreincr, l Lm tate Hydraulic Engincer and bead orplant operations at samncil D, l ~ranted to 12:-r a f;i�v minutes; I to coin mctiI tin ona of your entployces, Dove Brunk, 'who has just completed tir-1=xciwion feed, Breaker' and Station Service Switclseear instalindon 2, our project, In tno recent p59t'.sc have had 5eY=rel joy,; ctoa- by 000d oetsidc cont, ho±D_v: li the most eo��eterit p!mun v.1c havc ever had. D2Ye not onlyvrorl , extrzmely Maid b=Ji h'; the=o:firy, h7awUvae, , i and good cm-nman sense to provide quality resultS. Dave also has ver} pod p=opt= :,d rro,i:z;ional si lis u allomvin- his mien to work producd-vely as well is maintaini;t- a -cod refatian.31110 t t:a Ow 5voit iofca' t �I^ is pm 211 iTwH food eaten, end a Dlecsturf to he ?Sound, Evcryont has bzen liri::_'.: 5i im H5 wQrr—%' " Charlie Kcrtpi Osage Plant I ` �. •:. ... _ � -moi: r ,;._ice_' Y iitr~ 'r�eper�c�ir:e� o � B-i�o�.og u ' couch-, Ceit,tV, Mr, Paul l=ick. Office Manager Schneider Electric Company P.O. Sox 1049513 Jefferson Cit)r, k4issour1 65110 Dear Ails'_ Pica: This is a brioF note to io, you knov., what a great jou Reed Cr-ath and his Whsle crate did for us on the Biology F7o�r of CoUlter Science Canter as they r;4eGed our lighting in offices, iabaratodes, 'and ('4iss r000rns. All four cx,' us in lh=- dvp2r`irncrt`. Ware a bit apprehensive as Jle worrkGrs moved to our level. Mlcrosp'opes, computat-s and other expensive ,equipment vias out and we were coricemE,.3 as to ioss or damage. Our tears Were uinfoundsd as R= -Fd and his crew riloved viiih care and 6-61i [.Idoing their fob. They 1 -;EFL- m;! h�'ptul and very careful o- ail o, ou. equiptiient and of US. Please relay our ihankl: to t )em and Ist them know they can rcmia b- cl; aoaln and take 2-' courS-3 inNolog j. You are leery f+7 unn s to hav; a qualtt- t't�;'4�r5 S'1 ,r7 �S them in your emp+.o f. 5incar ly, _ r H. Wardn�rw Willi; m,,5, Professor of Biology ;:01 tVEST(YM iSTER AVENUIE 3 i-tfb i Z-3361 :��� . _ _ - i -• +•, ,'s stili=',,4� �•�i.�1. �'` ;krq +r' 'vsr+,C— f` Tt .� .. ,�'.•-=.� ...,. '-Yti,',:..'.ti.- :: Y.r::..� ,..t.'. _ �..�::�...�:...:•_.ti.....r-.�,:����'�.;�11�� _ . 7,�;-i� yi�.� r•.js..LfY }t5�� L rtr,�� vsi•;�'s. 4 •�_�, .�] _}r. 1s s�,•„�t F. ..�:.�•'1r.'!;i r• sn..: �. ; to A �Gaa�lill[lI9Ft�?1f?$CFi1:�i• •j -.i f is rl:�lrf 5l.lndaRlri=l CL - tnsis,g0 Gild? �vtc4rirz�CF�,i fA.i:31d,617.53r72 . 1C&,92772.-1180 8 U. S. POSTAL SERVICE 225 North Humphees Boulevard f,Aorriptlls, TN 88166-0040 RF: t r-Kinlo)r High School Cantrac; Amount: s03, o0_ Gentlemen: 1: S x�ssociat�s Ns used Sclineidgr Elsclric Comp -any ❑n humerous Including Ills el7are t2ferenGe pro)ecr . SchnsldQr 1=12cirlc has always P_J-'med in a prblessional Pnd compatont rnarmer. We consider the quality cqrid -- mucl 1' acq olt their,1 orl-,as P--rtor, Yd(tr Is the ra�ann ti';n t'3fy on ti'r�:,; I�r ir If I cart be of [Udther essi ML-ance, me. sincerely, /t.ERAL CONTTIACTWIS. Thomas. J. !Crash 'art=an Geyera[Con]raciors'ConsRrueUan Ma:r:;;•, SSSS 4Y9s� Patk A7ense 5:. l jel;. t.10 €a t r D-11-0 Ftt: f31,] 1547.1341 - ,•r=� ht:�:!!:y'�•ror_ta;tt:�c�rp,car,. November 1, 2001 1 Schneider Blectric t;onlpany 61 15 Evelirke St. Louii, MO 63139 Re, Job 07020 City of St. Louis Water Division Presedirnentatiort f Grit Basins &- Softening Basin Improvements Ft the Chain of Rocks Water Tleatm,-nt Plant - P111sc 1± Ladies and Gentiemea: As eve approach the ; rial close-out of the abovz-referenced project, Nve lite to extend our thanks to you and your company foo your dedication and coaperatian in to make this lncther successful project Nvith Tarlron. We truly appreciate your efforts in ell aspects of the construction process, aid hop- that soon be 3vorking together on another exciting and enjoyablc project. Please do not hesitate Lo contact us -%Vith any questloi s or cOica]-D3 0" er+y oir�C project. Sinter y, f I ivlatth€1_ Pfund Project Manar�zr amf i 3.{ cL CA,rirUtiii+f�J i KOTii5Cfl+ PEP, V—D 1 M tttor r4 to+o,totMantsll�at7L5 i JUHH?Vrit1MUS, Ph.D. Di r�T1+la�; eicnixa IfPEDLIab-VtlEL C:'tn_ -1 Reem"t Nr'n.a s �A.w-L t WP ELFT. TRIC J•. C, �i"r�'"ri�►C.4iEE`IE5,�4S,g.� ' 'IQ - J.��'t� f9••- L'.�t�saEva -Sct110-A. Elatau��tXJSC��Tta9,14t[3, YtY aRNMT, RA.,it3Yr. STATE of M1SS4JRi DOSE=PtI LC, 71F.PATE'1'ti1i:�'I't1i=)rfik:;trltl�lttsii�,71! �rn:?ra�+c4 D[vmoxor- COM i'itEt;E_tis vEPsYciiwi csLRvtcEs kIJLTON STATE HOSPUAL t;r_� Easy Sttt Scrcec Fuitor, MO 6525)-1193 k'itor�: (31-1) ,Sn- 100IFax-. (314) 592-3WO TDO: (314)592-3- 93 - • schnalder Iflactric Company P.O. Box IL�9a� jef" arson City, Missolirl 65101 �cntierr�e��: . On Augus< 12, ��9a, Fulton Stat: Hospital had a 3OU KVr' pry s}`pa Tre�sforttiei damaged due io flooding Qi the equipment roar, and bssetrien', a8a o� bur Adult Psychlafirio Sr-�--rvlces building, 7hc -fiood111g ccluspmajor tlamag to 3?le trinsformer 2nd other equipmant ,rhich resulted in the OvaCUIE"011 at o jL, patlent care bulldIng and limited sarvlcas io another p•,-:�tient care tiuiiding. I Flowever. il�anks �o tho, friendly, Gulck, and kno-•rledgeabia sup;por si�d r�spo ►se Claude hemp, our Pleat =?sintenEince Engineer, and his stalt r�cei°,ed FromPahl Fir-% and your company, this power Outage Was resolved viilh a tilnlm�!l a*dottn� of inConvec�ienc� jo our clients and Staler please accept our sincere lhaunE,s for all the support aild ; ssistance during August. Yaur help lessaned the iraluma greatty. It is vn hD,tor and e pleasure is do ]susiness with a cornpany and staff like, yours - Respectfully, J, Kenneth Lyle, Jr. Assistant 5up�rintpndent, Administr�iion f=a0 �s.-c EcaaJ� { oCr�tw.,�t�„��Gszot 4 Phom:31419 -45-f5 TO 1WHOM IT MAY CONCrnFli l' ne-garding: K-Teoh Corporalion i diblzt Sclinelder Eleclrlc St. Louis, MO. i ' We yrould recommend Schwaider Electric Company for any or mirtflr f electrical 5-; ori:.- They ha,(e successt IVY completed m -:111y jots for iloona 1-losp111a) Cenlsr. The mom recent 1-najor jab completed was th;3 Soulh Addition prola'-- 7111a proJ�,,� was a major expansion to olir liosp►ta,l and lfidvd--�d tiie addition Gf 3-5,000 S.1. of building with faur r��yt Cardiac Caihcd ation rooms and the ed�iilan Qf iti'ro eparaft)g roun)s. This projed &Esa lcictudcd aPVJYr lmatety ,b of ron�aJgi sx ork lncl�tdirr� purl«blay. -nie total contract far the e€cctricai }-�o;t. for i�nis prcjset was EIrp=.Jnd $900,000,OQ. Vyo foutici the quality of their to UP- ar,captlonal S',itl eery I:tils changes. We found all tktelr stall in the GYId,,e 1�rtoried�cal�la. �r,- Ql�ice st�:tY is veal professional arld h9lPful. It is a pisasure Lo wank vi'ith Schneider Neclric Company. 1; }:: � hive any alueslions or feel you need additional Information, please Y io eotrla rr,�o Sincerely, HOONE HOSPITAL CENTER r Dari Bascl:m�n, • Project Manager •t i fJ�l�i: �d i ys c�c� � E�•11 U•i 51..�GTr 1 C Ptn;�•}^�i 1 �iG �� 1•. •. ' Fcnc�'ia.;ry i7tlparme�t j 1yPt U'OUiF2VAYCJW9 - r'�.t nrr�.� na�iicrtgr SLtofhs.+V� -VVYW Irs•ago J 3Jd•23J•t896Jas z lY UNION �n To r;hom it 7npy cp,occrn. ��.T.�,LeS.t-S�.�r�ri'nrrr�nnce. uj �.CltJi��der Ftcciri� Schuclllcr L1eCtrlc -mns n7arftO nud l,as sucecssrtiljj cotupIctud Jr_ i:sslnit�(fon of burncr cootruls uu t5fo of Cie 640 lyny Cf7nl rlt-cd LDi.Fers nt c•ur L-vbathe I?Ilut-Htt,lu 111e pint year_ Thi` npproKbiLgte -FP-Tues of thu canb-rccts zierc �1�p,aGC} nutl � 30,07. tbricfJcr fr•rformed ltae jobs L a proD:��iorz1 wRivtcr and caa schedule. Doclt-k U on (;-jr tUrrc:: flppro,xl bldcict-'s T.'rsi for nll dretricnT --;ork nt OVZY P)P.nt.5. You tr-ttlti• you[ -.5, J_ Z.',r}iLl, Settlor f �, cr PROST BUILDERS., INC, the 9th Jet(crson City, h(a. 6510 Colvmbi�, ]4i'uou:S 653hy (314) 6354271 13141 4•i°- au FAX P14) 63; 2442 FAX (]14j 44V 9 INOU5TFUAL • CQM7vTMOAL • I1*TSTITUTiONAL • ECCLE_STASTTCAL *.-RUTURATf4N i - Schneider Electric Company 80;< 104955 Jeffex'son City, Ma 65110 Attp-rition: DeTini.s Hay8inger subject: 14issouri Division of EniployimeWt Security Tnterior Renovations and Misce? leneous Exterior Modifications Package pr©sect NO. 03-530-•90-0004 {E} Congratulations E i Dear Dennis, 1 Prost Builders would like to thank you for all youz7 help x, making this a success�vl project_ The client representatives stated howpleased the}' lore with, the cons tr-uc,ion v=" at the August 4 Opera, ,douse. please make sure the vErS cus `I t:i1O worked on this project kno-,, that we alrpeci ate theirwork- a:n-6 the DEE t they played -in the success of this p-'-o70ct. 5 appreciate your Ltajty Wim?')% aIldC)br,, iQL-tc£d tC] you again. 1 k:ds��t�ull}f, - Project Mariager r.tt;-�chment . Emply a tint Security nui ? dinG ():)ea yious�— cc: project File I • ..7.^ 13.ry'- - ..� �. - _ .ti� .4•}..'-•_ _ ...��; ._� ice,' '* e%� `: �'. '_.: . -�--3 TYY y1- �w"y;• •_ -'• 7�y�1yy�s.rxr- T+. -'r` ' •.ed: M1� y'J�— . �.--. .��. • .. .. .-r+. 2•".ri•.1_.�.0 .,. ,_ � •r�'i: -?ate �. . 1000 7ernes skive Monroe, Michipart 481-61 TEL: {313} 24J-1832 FAX: (3J3) 941-50W Mr. Bob Unterreiner �c.7-in�id�r irl�ctzic - - p_C.-50:� 104950 Jelarson City, mfs.;auri €5110 Bob, ' 1 lvould like to Wke 3his bre to tnen{ you and your outstanding cr--4v on this ymri; th= IU�ey hzvr pelo i-d in cur Data P1�r,t• Due to our eAremely bohh sc- n � � • _ � du1_ on [his project, �'.•�: �,. ere�.,i- I�a to r»; ger cu_.oiT;,, •. sct-tc-dules with your help. Your c. evi tiVf-=r? Y'ery herp ul, cou-lwvjs and per iorTil�-nd outstanding with E':"aiy fisziva 1 had during my EIF-ys si Eldon. You can be very pr©u di ofthem and pte:as_ cE-ss on m, tharks and-ppr=cl2!Jan to ez � oi' sham. 11 iS indeed a plezzum to cnntr m ar tl}cx understands Vis cuskQrn; rs' concern. 1 wouid not h_sRaIed to use ycur ca.-npanf zGer coast-pion for FU! Lire 'w*' IK Lias mz b- naedad. - � Sinc�ral�r, Merry r4sch i`�lar�g�r, Fedr�:lis Ensin_eri� - J Kr<mg